Tender For Landscape Plantation Works PDF

TENDER DOCUMENT
YEAR 2010-2011
Project Owner:
Mahindra World City (Jaipur)Ltd

411, Neelkanth Tower#1,
1,Bhawani Singh Marg, C-Scheme,
Jaipur-300201
Ph.No:+91-141-4007025
Master Planning Consultants Landscape Consultant:
JURONG Consultants Pte Site Concepts International Pte

Singapore Singapore
Project Manager & Site Coordinator
Manager, Urban Planning, Deptt. Of Infrastructure,
Project Office, Mahindra World City, Jaipur.
Near Kalwara Village,Off-NH#8, Jaipur-302037
Ph.No :+91-141-3003415
Mob.No :+91-9929093361
LANDSCAPING-PLANTATION WORKS in Mahindra World City, Jaipur

Landscaping Plantation Works in Mahindra World City, Jaipur
TABLE OF CONTENT
SECTION-1 : TENDER NOTIFICATION
SECTION-2 : FORMS FOR TENDERER DECLARATION
SECTION-3 : PROJECT DESCRIPTION
SECTION-4 : CONDITIONS OF CONTRACT
SECTION-5 : SPECIAL CONDITIONS OF CONTRACT
SECTION-6 : PLANTING MATERIAL SPECIFICATION & BILL OF QUANTITIES
SECTION-7 : LANDSCAPE DRAWINGS
Page 1 of 60
SECTION-1
TENDER NOTIFICATION
Page 2 of 60
1. NOTICE INVITING TENDER
Selected item rate tenders in the prescribed form are invited from experienced Contractors, for the following
work:
1. (a) NAME OF WORK Landscape (Softscape) Works @ MAHINDRA WORLD CITY @

JAIPUR
LIGHT ENGINEERING SECTOR SPECIFIC SEZ
PACKAGE-1: AREA OF LANDSCAPE =Approx. 153,565 sq.mt

PACKAGE-2: AREA OF LANDSCAPE =Approx. 113,776 sq.mt
TOTAL =Approx. 267,341 sq.mt
HANDICRAFT SECTOR SPECIFIC SEZ

PACKAGE-1: AREA OF LANDSCAPE = Approx. 200,611 sq.mt
PACKAGE-2: AREA OF LANDSCAPE = Approx. 26,518 sq.mt
TOTAL = Approx. 227,129 Sq.mt
DOMESTIC TARRIF AREA(DTA)

PACKAGE-I : AREA OF PLANTATION =Approx.25,000 Sq.mt
TOTAL =Approx.25,000 Sq.mt
Currently the landscape work is being processed for the package
specified as Package-1 which involves primarily Soil Preparation &
Tree Plantation with some focal point creation by few selected species
of shrubs & ground covers.
1(b) LOCATION: Mahindra World City, Special Economic Zone, PO- Mahindra World City
Near Vill:Kalwara,Off-NH-8(Jaipur-Ajmer Road)
JAIPUR 302 037.
Area under Development Phase I Phase II

Light Engineering SEZ =250 Acres 132 Acres 118 Acres
Handicraft SEZ =250 Acres 139 Acres 111 Acres
DTA =200 Acres 143 Acres 57 Acres
2. CLIENT MAHINDRA WORLD CITY (JAIPUR) LTD.,
411,Neel Kanth Tower, 1,Bhawani Singh Marg, JAIPUR-302021
3. E.M.D Rs 50,000.- Shall be taken after negotiation with the successful bidder. The
EMD shall be deposited in the form of Demand Draft in favour of
MAHINDRA WORLD CITY (JAIPUR) LTD.
4. PERIOD OF January 2011 to April 2011
EXECUTION
5. LANDSCAPE SITE CONCEPTS PVT. LTD,
ARCHITECTS 5/1, 4B, Fourth floor
Richmond ,Bangalore-5600026
6. AVAILABILITY
a) Blank Tender Forms shall be available to the shortlisted Contractors at
OF TENDER
the project office of Mahindra World City(Jaipur)Ltd on any
working day during office hours, on or before 31.12.2010.
OR
b) The Bidder may download the tender document from the web site of
Mahindra world city by clicking the link given below:
http://www.mahindraworldcity.com/content.aspx?act=tenders&citi=jai
pur
7. PRE-BID All the tenderer shall be open to have discussion on clarification as
MEETING required on any terms and conditions of the contract BEFORE signing of
the Tender document.
Page 3 of 60
8. TENDER FORMS a) No corrections or alterations in the form, nor in the conditions

stipulated therein, shall be made.
b) All drawings and documents issued along with the tender shall be
returned along with the submitted tender, duly signed by the tenderer.
c) The tender shall be drawn only on the form furnished with these tender
documents and duly signed. Tenders shall be complete in all respects.
9. VALIDITY OF a) The rates quoted by the contractor should hold good for at least (6)
TENDER months from the date of submission of tender.
b) Tender if accepted should hold good till the completion of the work.
10. TENDER COVER a) The tenders shall be submitted completed in all respect sealed with
cover labeled on top as TENDER FOR LANDSCAPING
PLANTATION WORKS IN MAHINDRA WORLD CITY
(JAIPUR) LIMITED, This cover shall also include the demand draft
towards the Earnest Money Deposit (if Applicable)
The tender shall be addressed to:
Deputy General Manager (Contracts), Project office, MAHINDRA

WORLD CITY (JAIPUR) LTD., Near Vill: Kalwara, Mahapura-
Kalwara Road, Off-NH-8 (Jaipur-Ajmer Road),Jaipur.Pin:302 037
11. SUBMISSION OF
a) The tenderer must submit sealed tenders, duly signed and completed in
TENDER
all respects, to the office of Deputy General Manager (Contracts),
Project office, MAHINDRA WORLD CITY (JAIPUR) LTD., PO-
Mahindra World City, Off-NH-8(Jaipur-Ajmer Road),
Jaipur.Pin:302 037 latest by January 07th, 2011.
b) In the event of the tender being submitted by a firm, it must be signed
separately by each partner hereof or in the event of the absence of any
partner, it must be signed on his behalf by a person holding a Power-
of-Attorney authorizing him to do so, such Power of Attorney to be
produced with the tender, and it must disclose that the firm is duly
registered under the Indian Partnership Act.
c) Receipt for payments made on account of a work, when executed by a
firm, must also be signed by the several partners, except where
contractors are described in their tender as a firm, in which case the
receipts must be signed in the name of the firm by one of the partners,
or by some other person having authority to give effectual receipts for
the firm.
12. CONTENTS OF
a) The set of tender documents issued for the purpose of tender shall
THE TENDER
comprise of the Tender Notification, Site Description and Scope of
DOCUMENT
Works, the Conditions of Contract, Special Conditions of the Contract,
the General Specifications & Bill of Quantities, and the Execution
Drawings.
b) The tenderer is expected to peruse all instructions, conditions, forms,
terms, design criteria and performance specifications, and drawings in
the tender documents. Failure to comply with these requirements of
tender submission shall be at the tenderer own risk.
c) At any time prior to the last date for submission of tenders, the
Employer may, for any reason whether at his own initiative or in
response to a clarification requested by a prospective tenderer, modify
the tender documents by the issuance of an Addendum.
d) The Addendum will be sent in writing or by telex or cable or E.mail to
all prospective tenderer who have received the Tender Documents and
will be binding on them, irrespective of whether the prospective
tenderer acknowledges receipt of the same or not.
Page 4 of 60
e) In order to afford prospective tenderer reasonable time to take the

addendum into account for the preparation of their tenders, the
Employer may, at his discretion, extend the last data for the
submission of tenders.
f) The tender prepared by the tenderer, all correspondence and
documents relating to the tender exchanged by the tenderer and the
Employer, shall be written in the English language only. Supporting
documents and printed literature furnished by the tenderer may be in
another language provided they are accompanied by an appropriate
translation of pertinent passages in English. For the purpose of
interpretation of the tender, the English language shall prevail.
g) Documents to be furnished at the time of tender submission.
The tender to be prepared and submitted by the tenderer to the Employer

for consideration shall comprise the following:
i) A covering letter from the Tenderer detailing the various

considerations in his tender.
ii) A list of all the documents accompanying the tender.
iii) Form of Declaration and Appendix thereto, duly signed along
with the complete set of tender documents.
iv) Detailed report on the tenderer's methodology of work,
deployment, prioritization with sufficient details to enable its
technical acceptability and ensuring completion of work within
the stipulated time schedule.
v) Information on eligibility and qualifications, together with
additional information regarding tenderer's management or
financial position, current works in hand etc.
vi) Detailed provisional Schedule & Program for completion of
various items of work including a network for all preliminary
arrangements for mobilization of resources such as manpower,
plant and machinery, and a chart giving forecast for principal
quantities of work proposed to be executed monthly. Again,
plantation being sensitive to the climatic condition, the work
scheduling should be prepared in accordance to the climatic
consideration for early completion of the work.
vii) Details of establishment and deployment, together with a
detailed organization chart, proposed for this project.
viii) Latest income tax clearance certificate from the concerned
department in India.
ix) Any other material required to be completed and to be submitted
in accordance with the tender documents.
b) All documents issued for the purpose of tendering as described shall
be deemed and have to be incorporated in the tender for the work.
13. OBLIGATORY a) All tenderer shall include a statement giving the following particulars:
REQUIREMENTS i) Major items of Equipments, Tools and machinery proposed for
use in carrying out the Contract;
ii) The qualifications and experience of key personnel proposed for
administration and execution of the Contract, both on and off
site;
b) In addition, the tenderer shall furnish the following information
regarding the financial standing of the tenderer:
i) Level of working capital;
ii) Extent of access to bank loans or credit facilities, with ceiling
limits, if any, prescribed in this regard and certified by the
bankers themselves;
c) Details of current work in progress including value, current
outstanding payables etc.
d) Shall submit the copy of this document signed on each page along
Page 5 of 60
with seal of the organization.
14. OPENING OF a) The tenders will be opened at the project office of MAHINDRA
TENDERS WORLD CITY (JAIPUR) LTD
b) The tender shall remain open for the acceptance by the competent
authority for a period of three months from the date of opening of the
financial bid.
c) Tenders once submitted cannot be withdrawn.
Page 6 of 60
2. CONDITIONS TO TENDERERS
1. SITE VISIT a) The tenderer shall, prior to submitting his tender for the work, visit
and examine the site of works and its surroundings at his own
expense, and obtain and ascertain for himself on his own
responsibility all information that may be necessary for preparing
his tender and entering into a contract, and take the same into
account in the quoted contract price for the work.
b) The tenderer shall satisfy themselves about the following factors:
i) Site conditions including access to the site, existing and
required roads and other means of transport/communication for
use by him in connection with the work including diverting and
re-routing of services.
ii) Requirement and availability of land and other facilities of his
enabling works, establishment of his nursery, office, stores etc.
iii) Ground conditions including those bearing upon transportation,
disposal, handling and storage of materials required for the
work or obtained there-from.
iv) Source and extent of availability of suitable materials,
including water etc., and labor (skilled and unskilled) required
for work, and laws and regulations governing their use and
employment.
v) Geological, meteorological, topographical and other general
features of the site and its surroundings as are pertaining to and
needed for the performance of the work.
vi) The limit and extent of surface and subsurface water to be
encountered during the performance of the work, and the
requirement of drainage and pumping.
vii) The type of equipment and facilities needed, for and in the
performance of the work;
viii) The extent of lead and lift required for the work in complete
form over the entire duration of the contract, and
ix) All other information pertaining to and needed for the work
including information as to the risks, contingencies and other
circumstances which may influence or affect the work or the
cost thereof under this contract.
c) The tenderer should note that information, if any, in regard to the
local conditions, as contained in these tender documents, has been
given to tenderer merely for guidance and is not warranted to be
complete.
d) A tenderer shall be deemed to have full knowledge of the site,
whether he inspects it or not, and no extra charges consequent on
any misunderstanding or otherwise shall be allowed.
e) The tenderer and any of his personnel or agents will be granted
permission by the Site-In-Charge or his authorized nominee, on
receipt of formal application in respect thereof a week in advance of
the proposed date of inspection of site, to enter upon his premises
and lands for purpose of such inspection, but only on the express
condition that the tenderer (and his personnel and agents) will
relieve and indemnify the Employer (and his personnel and agents)
from and against all liability in respect thereof and will be
responsible for personal injury (whether fatal or otherwise), loss of
or damage to property and any other loss, damage, costs and
expenses however caused which, but for the exercise of such
permission, would not have arisen.
Page 7 of 60
2. TIME LIMIT a) Time is of the essence in this Contract, and the work covered herein
is required to be completed in all respects within the time period
stipulated above.
b) The tender should be based on this time of completion. However, the
above-mentioned stress on time-based completion shall not entitle the
successful tenderer to claim price escalation for the portion of work,
if any, which remains unexecuted after the stipulated completion
period.
3. TENDERED The Contractor must understand clearly that the rates quoted are for
RATES complete work and include all cost of materials (plants and other basic
requirements like staking, safety requirement of the planting materials,
signages (planting nomenclature), costs due to labor, tools & tackles,
supervision, services of all types like use of electricity, watering, transport
of water for planting materials, works, power royalties etc., including
their procurement, transportation, storage and wastage etc., to cover the
cost of night working, when and if required. No claim for additional
payments beyond the prices or rates quoted will be entertained. The
Contractor shall further provide without extra charges all labor and things
required by Landscape Architect/site In-Charge for testing (soil & water
on continual basis) and measuring the work and for weighing, measuring,
providing or testing the appropriateness of any portion of the work, and
shall also at his own cost provide access to every part of the work with
safety.
a) The contract shall be for the total cost as quoted in the schedule of
quantities, attached by the successful tenderer, complying with the
terms and conditions of tender document and shall be for the whole
work as prescribed in scope of work.
b) All duties, taxes, fees and other levies (present and future) payable by
the Contractor under the Contract or for any other cause, as on the
date thirty days prior to the closing date for submission of tenders,
shall be included in the total contract price submitted to the
Employer.
c) The rates must be inclusive of ESI, PF or any other statutory
compliance as applicable and all taxes inclusive of Entry Tax, Sales
Tax, Turn over Tax, Works Contract Tax wherever applicable. The
Employer will not reimburse any of the above-mentioned items.
d) The rates in the tender should be quoted both in figures and in words;
and these are to be written in ink only and are not to be typed; and all
corrections should be dated and attested by the Contractor with full
signature.
e) If there is any difference between the rates quoted in words and those
in figures, the lower rate shall be taken into consideration.
f) It should be clearly understood that the quantities shown in the Bill of
Quantities are approximate, and the drawings are tentative and liable
to modifications or alterations as may be found necessary.
g) The Contractor shall be deemed to have satisfied himself before
tendering as to the correctness and sufficiency of his tender for the
works, and the prices stated in the schedule of quantities and/or the
schedule of rates and prices, which rates and prices shall cover all his
obligations under the Contract, and all matters and things necessary
for the proper completion of the works.
Page 8 of 60
4. VARIATIONS OR a) The tenderer shall submit an offer which complies fully with the
DEVIATIONS IN basic requirements of the tender documents as indicated in drawings
TENDER and specifications.
DOCUMENTS b) All tenderer are cautioned that no conditional offer, variations or
deviations by the tenderer, with respect to any items proposed by the
tenderer (including advance loan for mobilization or time for
completion etc.), shall be entertained or considered.
c) Furthermore, any deviation from Contract conditions, particular
specification, or other requirements stipulated in these tender
documents other than those especially clarified/amended shall be
liable to be rejected as non-responsive.
5. CORRECTION OF a) Tenders determined to be substantially responsive to be checked by

ERRORS the Employer for any arithmetical errors in computation and
summation.
b) Where there is a discrepancy between the unit prices/rates and the
total amount derived from the multiplication of the unit price/rate and
the quantity, the unit price/rate as quoted will govern.
6. DISCREPANCIES a) In case of any inconsistency between bill of quantities, performance

IN TENDER specification and drawings, the following order of preference shall
DOCUMENTS prevail:
i) Bill of quantities
ii) Drawings
iii) Specifications
b) Any discrepancy in the Contract documents should be brought to the
notice of the OWNER for clarification, before submitting the tender.
c) No claim in this regard shall be entertained after the acceptance of
the tender.
7. UNSUCCESSFUL The earnest money deposits of the unsuccessful tenderers will be

BIDDERS refunded immediately after the tender are finally disposed of, or after
three months from the last date of the opening of the financial bids.
8. SUCCESSFUL a) The successful tenderer shall, within 15 days from the date of issue
TENDERER of the intimation of acceptance of his tender, execute an agreement
on a stamped paper of value of Rs.200/- in prescribed form, failing
which the earnest money shall stand forfeited to MAHINDRA
WORLD CITY (JAIPUR) LTD
b) In the case of the successful tenderer, the E.M.D. shall be converted
to Security Retention Amount, which shall remain with the
Employer, free of interest, as a security deposit for the due execution
of the works and completion of the Contract, and which will be
adjusted to 10% (Ten percent) in the Running-On-Account Bills.
c) A retention amounting to 10 % (Ten percent) of the gross amount of
each running bill will be deducted at the time of certifying interim
payment, for the due execution and completion of the work under
Contract. This retention amount is liable to be forfeited, partly or
wholly, if the Contractor fails to carry out the work or to keep up the
desired rate of progress.
d) Out of the above, only an amount calculated at 10% (Ten percent)
on the total value of work shall be retained by the Employer, free of
interest, from the final bill of the Contractor, during the defects
liability and maintenance period of 12 months starting from the time
of the virtual completion of work as certified by the Landscape
Architects/Site-In-Charge.
e) This amount shall be returned to the Contractor on completion of the
defects liability and maintenance period, provided that the
Contractor has attended to and rectified all the defects, if any, shown
to him in the work executed by him, at his own cost, to the
satisfaction of the Landscape Architects/Site-In-Charge, or after the
final bill is paid, whichever is later.
Page 9 of 60
f) Withdrawal of the tender when it is once accepted, or failure on the

part of the successful tenderer to execute the Contract agreement
within the stipulated time after intimation of acceptance of the
tender, would entail forfeiture of the Earnest Money Deposit.
3. GENERAL CONDITIONS TO THE CONTRACTORS
a) The Conditions of Contract, as stipulated hereunder, shall bind the Contractor.

b) The Contractor will have to make his own arrangements for electricity or if in case the same being
provided by MWCJ, then the contractor shall install a meter and pay their use to the MWCJ @
standard applicable charges.
c) MWCJ shall provide water for all use but contractor shall be liable and answerable to its uses. Any
waste of water by any means shall be liable the contractor to be fined as decided by the competent
authority
d) The contractor shall create a small office place, storage for materials, along with a nursery
establishment fitted with irrigation system to maintain their planting material in good conditions before
plantation. The space provided by the employer shall be required for execution of the work and should
be equipped with all his tools, tackles & machinery which may be required for the speedy execution of
work. Labour Camp should preferably be out of the development area, however living arrangement for
a guard or a Mali can be made provided the arrangement is screened off and has been maintained in
hygienic conditions
e) Work should not be sub-let, without the written consent of the Employer.
f) The site for the work shall be made available in parts as per site conditions.
g) All the conditions set-forth in the schedule of the Contract form are binding on the Contractor.
h) Further particulars in connection with the works can be had from the office of M/s Mahindra World
City (Jaipur) Ltd during office hours.
i) The competent authority reserves the right to reject any or all tenders without assigning any reasons.
j) In case of any dispute, the decision of the Landscape Architects shall be final and binding.
SIGNATURES AND SEALS:
Contractor: M/s. ____________________ Employer: M/s. ____________________
Page 10 of 60
SECTION-2
FORMS FOR TENDERER
Page 11 of 60
FORM OF ARTICLES OF AGREEMENT
ARTICLES OF AGREEMENT made the __________ day of __________2010,

Between MAHINDRA WORLD CITY (JAIPUR) LTD., (hereinafter called the Employer) on the one part
And
M/s. ____________________________ whose Registered office is situated at
_____________________________________________ (hereinafter called the Contractor) on the other part.
WHEREAS the Employer is desirous of Landscape works, and has caused Drawings and Specifications etc. describing
the work to be prepared by M/s. Site Concepts Pvt. Ltd., Landscape Architects,
And
WHEREAS the said drawings numbered ______________________________ and/or the Bill of Quantities have been
signed by or on behalf of the parties hereto, And
WHEREAS the Contractor has agreed to execute upon and subject to the conditions set forth herein (herein referred to
as the said Conditions, the work shown upon the said drawings and/or described in the said Specification and included
in the said Bill of Quantities at the rates therein set forth, amounting to the sum as therein arrived at or such other sum
as shall become payable there-under (herein referred to as the said Contract Amount).
NOW IT IS HEREBY AGREED AS FOLLOWS:
1. In consideration of the said Contract Amount to be paid at the times and in the manner set forth in the said
Conditions, the Contractor shall upon and subject to the said Conditions execute and complete the works shown
upon the said Drawings and described in the said Specification and/or the Bill of Quantities.
2. The Employer shall pay the Contractor the said Contract Amount or such other sum as shall become payable at
the times and in the manner hereinafter specified in the said Conditions.
3. The term Landscape Architect in the said Conditions shall mean the said M/s. Site Concepts Pvt. Ltd or in the
event of the death, or ceasing to be the Landscape Architect for the purpose of the Contract, such other person as
shall be nominated for that purpose by the Employer, provided always that no person subsequently appointed to
the Landscape Architect under this Contract shall be entitled to disregard or overrule any previous decision or
approval of direction given or expressed by the Landscape Architect/Architect for the time being.
4. The term Site-In-Charge in the said condition shall mean the person so designated by the Employer to supervise
the work.
5. The said Conditions and Appendix thereto shall be read and construed as forming part of this Agreement, and the
parties hereto shall respectively abide by, submit themselves to the conditions and perform the agreements in their
part respectively in such Conditions contained.
AS WITNESS OUR HANDS THIS __________ DAY OF __________ 2010.
Signed by the said CONTRACTOR Signed by the said EMPLOYER

In the presence of In the presence of
Address Address
Occupation Occupation
Page 12 of 60
FORM OF DECLARATION BY THE TENDERER Date: ------------------
From: To,
----------------------------------------------------------------------. The Head (Infra),
. Mahindra World City(Jaipur) Ltd
. Jaipur
Dear Sir,
I/We do hereby submit my/our tender for the execution of the work specified in the under memorandum, at my/our
quoted rates for each item specified in the schedule of quantities and items, and in all respects in accordance with the
specifications, designs, drawings, and instructions in writing as per the annexed Conditions of Contract.
MEMORANDUM
a) General description - Construction of Softscape Works at MAHINDRA WORLD

CITY (JAIPUR) LTD
b) Earnest money deposit (E.M.D.) - Rs.
c) Security Deposit to be deducted from the

running-on-account bills. - ..
d) Time allowed for completion of ..

construction. -
e) Amount put to tender - Rs. ...
Should my/our tender be accepted, I/we hereby agree to execute an Agreement to abide by and fulfill all the terms and
provisions of the Conditions of Contract annexed hereto, or in default thereof, forfeit the E.M.D. mentioned in the said
conditions, without prejudice to any other right of the Employer.
I/We hereby distinctly and expressly declare and acknowledge that before the submission of this tender, I/we have
carefully followed the instructions, read the specifications attached with the tender form and relevant ISI specifications
thereof, and that I/we have made examination of the Contract documents and drawings, specifications and quantities,
and of the locality where such work is to be done; and that I/we have taken these conditions into consideration while
preparing the tender.
I/We distinctly agree that I/we would not claim or demand upon the Employer, any claims based upon or rising out of
any alleged misunderstanding or misconceptions or mistakes on my/our part of the said covenants, agreements,
stipulations and conditions of the tender.
If upon written information to me/us by the Employer, I/we fail to attend his office therein before the end of the period
specified on such intimation, and if upon intimation being given to me/us by the Employer of the acceptance of my/our
tender, I/we fail to enter into the agreement with the Employer as defined in the tender notice, I/we shall be debarred
from the approved list of Contractors, in addition to forfeiting my/our Earnest Money Deposit already submitted with
the tender.
Any notice required to be served on me/us shall be sufficiently served on me/us if delivered to me/us personally, or
forwarded to me/us by post (registered or ordinary), or left at my/our given address.
I/We fully understand the terms and agreements of the Contract to be entered into between me/us and the Client, and
the written Agreement shall be the foundation of the rights of both parties, and the Contract shall not be deemed to be
complete until Agreement has been signed by me/us and by the Client.
Page 13 of 60
I/We fully understand that the Client reserves the right to accept or reject any or all the tenders, without assigning any
reasons thereof.
DATED THE __________ DAY OF _______________ 2011.
Signature of the Contractor
(Seal and address)
APPENDIX HEREIN REFERRED TO
SL. NO. TERM USED DESCRIPTION

1. Date of Commencement : Seven days from date of issue of work order.
2. Date of Completion : As per the schedule of the Work -in stages-Milestone

completion as per availability of the site.
3. Value of work for interim certificate : Minimum of 5% on contract.
4. Retention Percentage in the interim bills : 10% (ten percent)
5. Retention Percentage in the final bill : 5% (Five percent) after final completion of the plantation
and maintenance period for all the milestones as accepted
for Virtual Completion.
6. Period of Retention : 12 months from the date of virtual completion of the last
milestone as achieved for the package of work awarded .
7. Period of Honoring : 21 days after certification.
8. Period of Final Measurements of work : 15 Days after submission of Stage Completion

in stage completion as identified by
Contractor & Site-In-Charge
Signature & Seal
CONTRACTOR/AUTHORIZED SIGNATORY OF CONTRACTING FIRM
Page 14 of 60
SECTION: 3
DESCRIPTION OF SITE & SCOPE OF WORK
Page 15 of 60
1. BRIEF PROJECT DESCRIPTION MAHINDRA WORLD CITY @ JAIPUR,
SITE DESCRIPTION
The Mahindra World City, Jaipur(Owner) site proposed on spread of an area 3000 Acres is located off
Jaipur-Ajmer Road(NH-8) on Mahapura- Kalwara Road about 21 Kms from Jaipur Airport and 18 Kms from
Jaipur Railway Station. In the first phase of development, Mahindra World City, Jaipur started its
development with 383 Acres of IT/ITeS sector Specific SEZ and currently in state of expanding its
development to additional 500+ acres of development in two sector specific SEZs as Light Site-In-Charge &
Handicraft SEZ. Besides approx 200 Acres of Land is part of the Domestic Tariff Area (Non Custom Bonded
Area).
While, the Landscape works within most of the Ph-I (383 Acres) development area is on completion, Owner
proposes plantation works in its second phase of its development. The plantation works shall be undertaken in
stages as per the work package to be released accordingly. As the area is still under development stage, it is
essential to understand the basic problem as might be faced during the time-period of execution.
2. SCOPE OF WORKS
All the Softscape works, pertaining to the Landscape works, will have to be done at MAHINDRA WORLD
CITY @ JAIPUR as per the special conditions of the contract. The entire project area is primarily low fertile
with the basic nature of the soil being highly saline and almost zero percolation which allows selective
vegetation. While utmost care has been taken on landscape proposal for the area but plantation works require
dedicated effort for ensuring survivability of the planting materials requires appropriate level of expertise and
experiences in handling of the work .The landscape shall be in stages, primarily as per the availability of the
site after completion of the Civil Works on the desired stretch. The broad scope of work is mentioned as below
while the detailed performance of the contractor shall be gauged based on the schedules as provided in the
Section-5 of Special Conditions of the Contract.
1. SPEEDY WORK: Follow-up with the Civil Contractors for handing over of the site in desired
state for speedy landscape works. Owner shall not be responsible for any delay on account of the
said reasons whatsoever.
2. SITE CLEARANCE: The landscape Contractor shall ensure the area of concern to be cleared of
all the unwanted materials like cement mix, aggregates, debris, and wastes of any type or left over
of the civil contractors before starting his work. The same should be cleared off by the civil
contractor and to be followed-up by the landscape contractor. In-event of the same not being
removed off the site by the civil contractors, Landscape Contractor shall be required to get the
undesirable waste including wild vegetations cleared off the off the site as per instruction of the
Site-In-Charge. The site clearance and preparation shall be at no additional cost but form the part
and parcel of the landscape works. The site shall be signed of for landscape works only after sign-
off by the Site-In-Charge on joint inspection with the Landscape Contractor.
3. SOIL PREPARATION: Rough grading and earthworks per section 2 of the specification. This
work shall include the supply, placement, shaping of earth berms, and or excavation and removal
of unwanted soils to tip, as may be required and as indicated in the grading drawings, details and
tender documents. This section includes the setting and formation of rough grading to plus or
minus 15cm with suitable materials to achieve the level, berms and earth contouring as indicated in
the drawings and documents. This section includes the fine grading to finish levels to plus or
minus 25mm. The contractor shall be responsible for plantation works in the right soil medium
(pH-value not exceeding 7.5) besides other chemical composition suitable for planting materials.
The contractor shall be required to get the proposed good soil tested as recommended & accepted
by the owner for entire Landscape site at definite intervals (As per instruction of the site-in-charge)
as per instruction of the Site-In-Charge. Also the soil test shall be for the final mixture ready for
plantation and should be reported appropriate for plantation works. The test will be conducted on
behalf of the contractor by the owner and shall be liable for deduction form the landscape bill as
raised by the contractor on plantation works. Also the contractor shall be required to create
landforms (mounds & berms) as per drawing and instruction of the site-in-charge for facilitation of
the drainage and aesthetic value in the landscape area. This section includes the fine grading to
finish levels to plus or minus 25mm.The payment shall be on the basis of the total volume of the
earthworks payable in cu.mt.
Page 16 of 60
4. PLANTATION WORKS: The landscape contractor shall be required to complete the plantation
works as per the planting schedule provided in Section-5 of Special Conditions of the
Contract.
5. MAINTENANCE WORKS: The contractor shall be responsible for maintenance of the
plantations works as per the schedule in Section-5 of Special Conditions of the Contract.
Including general cleanliness of the landscape area for entire period of the contract.
Page 17 of 60
SECTION: 4
CONDITIONS OF CONTRACT
Page 18 of 60
1. ADMINISTRATION
Conditions Hereinbefore Referred to Words imparting the singular number include the plural number and
vice-versa
Terms Used : In construing these Conditions, the Specification, Bill of Quantities, Tender Notification and
Contract Agreement, the following words shall have the meaning herein assigned to them except where the
subject or context otherwise requires.
Employer -Shall mean MAHINDRA WORLD CITY (JAIPUR) LTD and shall
or Owner include his (their) legal representative/s, assignee/s or successor/s.
Site-In-Charge -Shall mean the person so designated by Employer to supervise the
work, or his duly authorized assistant.
Landscape Architects -Shall mean M/s. Site Concepts Pvt. Ltd. designated by the Employer
as Project Landscape Architects.
Contractor -Shall mean M/s. ____________________________________ and
shall include his (their) legal representatives assign/s or successor/s,
which individual/firm has undertaken the works by virtue of this
Contract.
Site -Shall mean the site of the Contract works, including any development
works, building and erections thereon, and any other land (inclusive)
as aforesaid, allotted by the Employer for the Contractor's execution of
the scope of work.
Works -Shall mean the works to be executed by virtue of this Contract,
or Work whether temporary or permanent, and whether original, altered,
substituted or additional.
This Contract -Shall mean the Articles of Agreement, the Special Conditions, the
Conditions of Contract, the Appendices, the Bill of Quantities, the
Specification, and the Drawings attached hereto and duly signed, and
the written instructions issued from time to time by the Landscape
Architect/Site-In-Charge.
All these documents taken together shall be deemed to form one
Contract and shall be complimentary to one another.
Notice in writing -Shall mean a notice in written, typed or printed characters, sent (unless
or delivered personally or otherwise proved to have been received) by
Written Notice registered post to last known private or business address or registered
office of the addressee, and shall be deemed to have been received
when in the ordinary course of post it would have been delivered.
Act of insolvency -Shall mean any act of insolvency as defined by the Presidency Towns
Insolvency Act, or the Provincial Insolvency Act, or any Act
amending such original.
Approved, Directed or -Shall mean the approval, direction, or selection by the Landscape
Selected Architect/Site-In-Charge/Employer.
Sl. Terms of Reference Description

No
1. Change in Constitution Where the Contractor is a partnership firm, the previous approval in
of Firm writing of the MAHINDRA WORLD CITY (JAIPUR) LTD. shall be
obtained before any change is made in the Constitution of the Firm.
Where the Contractor is an individual or a Hindu undivided family
business/concern, such approval as aforesaid shall likewise be obtained
before the Contractor enters into any partnership agreement where,
under the partnership agreement, the firm would have the right to carry
out the work hereby undertaken by the Contractor.
Page 19 of 60
2. Security Deposit The person/persons whose tender may be accepted (hereinafter called
the Contractor which expression shall, unless the context otherwise
requires, include his heirs, executors, administrators and assigns) shall
pay Earnest Money Deposit in the form of Demand Draft in favor of
MAHINDRA WORLD CITY (JAIPUR) LTD.,
(a) Deduct, at the percentage mentioned below, of all money

payable for work done under the Contract, at the time of
making such payments to him/them, and
(b) To hold such deductions as further Security Deposit.
Both E.M.D. and F.S.D. shall not carry any interest. If the E.M.D. is in
the form of a Bank guarantee, the same shall be valid for a minimum
period of 12 Months days. In the case of the successful tenderer, the
validity of this Bank Guarantee shall be changed for a period covering
the specified job work and maintenance period subject to further
extension of the contract period if extended.
E.M.D. Earnest Money Deposit - Rs 50,000/ for the work at

MAHINDRA WORLD CITY (JAIPUR) LTD., and
F.S.D. Further Security Deposit - @ 10% (Ten percent) on
Running-on-Account Bills.
3. Dues to Mahindra All compensation or other sums of money payable by the Contractor to
World City (Jaipur) MAHINDRA WORLD CITY (JAIPUR) LTD., under the terms of
Ltd., To Be Set Off this Contract may be released or deducted from any Security Deposit
Against Security payable to him or from the interest arising therefrom, or from any sums
Deposit which may be due or may become due by MAHINDRA WORLD
CITY (JAIPUR) LTD to the Contractor on any account whatsoever. In
the event of his security deposit being reduced by reason of any such
realization or deduction as aforesaid, the Contractor shall, within ten
days thereafter, make good in cash any such sum or sums which have
been deducted from, or raised by sale of his security deposit or any part
thereof.
4. Refund of security The 5% of the Security Deposit lodged/paid/deducted shall be refunded
deposit to him after the final bill is paid or after the successful completion of
Period of Twelve months from the date of virtual completion of work
and maintenance period thereof. The Security Deposit shall carry no
interest.
5. Definition and scope of The expression Work or Works where used in these conditions
works shall, unless there be something in the subject or context repugnant to
such landscape activities, be construed to mean the work or works
contracted to be executed under or in virtue of this Contract, whether
temporary or permanent and whether original, altered, substituted or
additional.
6. Work to be executed in The Contractor shall execute the whole and every part of the work in
accordance with the most sound and substantial and workman-like manner, and in strict
specifications, drawing, accordance with the specifications both as regard to materials and
instructions etc., workmanship. The Contractor shall also conform exactly, fully and
faithfully to the designs, drawings and instructions in writing relating to
the work signed by the Site-In-Charge or other competent authority and
lodged in his office, and to which the Contractor shall be entitled to
have access, during office hours, at such office or on the site of the
work, for the purpose of inspection. The Contractor shall, if he so
requires, be entitled at his own expense to obtain copies of the
specifications and of all such designs, drawings and instructions as
aforesaid. The Contractor shall also be responsible for the delivery of
assigned job as per complete satisfaction of the Site-In-Charge and the
execution of the work strictly in accordance with the specifications of
the work.
Page 20 of 60
7. Action where there is no In the case of any class of work for which there is no such specification
specification mentioned in the Contract, such work shall be carried out in accordance
with Landscape Architects specifications, and in the event of there
being no such specifications, then the work shall be carried out in all
respects in accordance with the instructions and requirements of the
Site-In-Charge or other competent authority.
8. Contractor bound by The Contractor shall be bound to carry out the work in accordance with
Site-In-Charge any instructions in this connection which may be given to him in
instructions writing signed by the Site-In-Charge, his authorized representative or
other competent authority.
Any instructions given verbally shall be noted in the Instruction Book

and got signed by the Landscape Architect/Site-In-Charge, or his
authorized representative, and deemed as instructions for the proper
execution of the work and, when considered necessary by the Site-In-
Charge /Landscape Architect, followed up in writing.
The whole of the work must be proceeded with in such sections and at
such times as directed by the Site-In-Charge /Landscape Architect.
9. Failure by Contractor to If the Contractor, after receipt of written notice from the Landscape
comply with Landscape Architect/Employer requiring compliance, fails to comply with such
Architects instructions further drawing and/or Site-In-Charge/Landscape Architects
instructions, the Employer, with the recommendation of the Landscape
Architect, may employ and pay other persons to execute any such work
whatsoever that may be necessary to give effect thereto, and all costs
incurred in connection therewith shall be recoverable from the
Contractor by the Employer, on the Certificate of the Landscape
Architect, as a debt, or may be deducted by him from any moneys due
or to become due to the Contractor.
10. Alteration in work The Landscape Architect, in concurrence with the Employer, may from
time to time issue further Drawings and/or written instructions, details,
directions and explanations, which are hereafter collectively referred to
as instructions" in regard to:
i) The variation or modification of the design, quality or

quantity of works or the addition or omission or substitution
of any work.
ii) Any discrepancy in the Drawings or between the Schedule of
quantities and/or drawings and/or specification.
iii) The removal from the site of the materials brought thereon by
the Contractor and the substitution of the other material
thereof.
iv) The removal and/or re-execution of any works executed by
the Contractor.
v) The opening up for inspection of any work covered up.
vi) The amending and making good of any work as executed.
The Contractor shall forthwith comply with and duly execute any work
comprised in such Landscape Architects instructions, directions and
explanations, given to the Contractor or his representative upon the
works by the Landscape Architect; which shall, if involving a variation,
be confirmed in writing by the Contractor within seven days, and if not
dissented from in writing within a further seven days by the Landscape
Architect, such shall be deemed to be Landscape Architects
instructions within the scope of the Contract. If compliance with the
Landscape Architects instruction, as aforesaid, involves work and/or
expense and loss beyond that contemplated by the Contract, then,
unless the same were issued owing to some breach of this Contract by
the Contractor, the Employer shall pay to the Contractor at the Site-In-
Charge/Landscape Architects Certificate the price of the said work (as
an extra to be valued as hereinafter provided and/or expense and/or
Page 21 of 60
loss).
Any alterations made to the work made based on technical;/aesthetic

values as per the instructions of the Site-In-Charge/Landscape Architect
shall be considered as part of the work undertaken by the Contractor
under this Contract, and shall be executed as such.
11. Alterations in work The Site-In-Charge shall have power to make any alterations in,
omissions from, additions to or substitutions for the original
specifications, drawings, designs and instructions that may appear to
him to be necessary or advisable during the progress of the work. If, for
that purpose or if for any other reason it shall in his opinion be
desirable, he shall have power to order the Contractor to do and the
Contractor shall do any or all of the following:-
i) Increase or decrease the quantity of any work included in the

Contract,
ii) Omit or delete any such work,
iii) Change the character or quality or kind of any such work,
iv) Change the levels, lines, positions and dimensions of any part
of the work,
v) Execute additional work of any kind necessary for the
completion of the works and
vi) Change in any specified sequence, methods or timing/priority
of landscape of any part of the work.
vii) Acceptance or rejection of the material not as per the desired
specification of the planting materials.
12. Orders for variations to No such variations shall be made by the Contractor without an order in
be writing writing of the Site-In-Charge. If for any reason the Site-In-Charge shall
consider it desirable to give any such order verbally, the Contractor
shall comply with such order and any confirmation in writing of such
verbal order given by the Site-In-Charge, whether before or after the
carrying out of the order, shall be deemed to be an order in writing
within the meaning of this clause; and if the Contractor shall within
seven days confirm the order in writing to the Site-In-Charge and if
such confirmation is not contradicted in writing within fourteen days by
the Site-In-Charge, it shall be deemed to be an order in writing by the
Site-In-Charge.
Any additional work which the Contractor may be directed to, in the
manner above specified, as part of the work, shall be carried out by the
Contractor on the same conditions in all respects on which he agreed to
do the main work and at the same rates as are specified in the tender for
the main work.
13. Variation not to vitiate No alteration, omission, deletion or variation shall vitiate this Contract,
Contract but in case the Landscape Architect thinks proper at any time during the
progress of the works to make any alterations in or additions to or
omissions from the works or any alteration in the kind or quality of the
materials to be used therein, and shall give notice thereof in writing
under his hand to the Contractor, the Contractor shall alter, add to or
omit from, as the case may require, in accordance with such notice, but
the Contractor shall not do any work extra to or make any deviation
from any of the provisions of the Contract, stipulation, specification or
Contract drawings, without the previous consent in writing of the
Landscape Architect; and the value of such extras, alterations, additions
or omissions shall in all cases be determined by the Landscape
Page 22 of 60
Architect/Site-In-Charge and payment to be on sole discretion of the

competent authority.
14. Determination of rates If the additional, substituted or altered work includes any class of work
for additional, for which no rate is specified in the Contract, then such work shall be
substituted or altered carried out at the rates specified for or derived from similar item of
items of work: work in the Contract. With regard to the question whether the
additional, substituted or altered item/items of work/works is/are similar
or not to that/those in the Schedule of Rates, the decision of the
Landscape Architect shall be final and binding on the Contractor.
In the absence of similar items in Contract, the Contractor shall within

seven days of the date of receipt by him of the order to carry out the
work, inform the Site-In-Charge of the rates at which it is his intention
to charge for such class of work, supported by analysis of the rate or
rates claimed. The rate analysis submitted by the Contractor shall be
based on actual prevailing market rates of materials, labor and any other
incidental charges, plus 15% (fifteen percent) overheads and profits,
inclusive of all taxes. There upon the Site-In-Charge shall determine the
rates or rates on the basis of observed data, and failing this, on the basis
of prevailing market rates. Under no circumstance shall the Contractor
suspend the work on the plea of non-settlement of rates for items falling
under this clause. In the event of any dispute regarding the rates for
such items the decision of the Landscape Architect shall be final.
15. Variations in quantity There may be large variations to the quantities mentioned in the Bill of
Quantities, and the Site-In-Charge reserves the right to decrease or
increase or delete any quantity of the item of work as required. The
Contractor should note that the rate quoted is per one unit; hence no
claims on escalation will be entertained due to variation in quantities.
16. No compensation for If at any time after the execution of the Contract documents, the Site-In-
deletion of work Charge or other competent authority shall, for any reason whatsoever,
require the whole or any part of the work, as specified in the tender, to
be stopped for any period or require the whole or part of the work (i)
not to be carried out at all or (ii) not to be carried out by the tendered
Contractor, he shall give notice in writing of the fact to the Contractor,
who shall thereupon suspend or stop the work totally or partially as the
case may be. In any such case, the Contractor shall have no claim to
any payment of compensation whatsoever on account of any profit or
advantage which he might have derived from the execution of the work
in full but which he did not so derive in consequence of the full amount
of the work not having been carried out, or on account of any loss that
he may be put on account of materials purchased or agreed to be
purchased or for unemployment of labor recruited by him. He shall also
not have any claim for compensation by reason of any alterations
having been made in the original specification, drawings, designs, and
instructions which may involve any curtailment of the work as
originally contemplated.
17. Possession of site for Every endeavor shall be made to give clear possession of site in one lot,
work and if it is not possible to do so, in more than one lot for which delay, if
any, no claim shall be entertained for the Contractor, but extension of
time of completion, if justified, may be granted, without affecting the
contract price.
18. Defects liability period If the Contractor or his workmen or servants knowingly or
unknowingly break, damage, deface, injure or destroy any part of the
fixed or part of unfixed development in which they may be working, or
any building, road, fence, enclosure or grass land or cultivated ground
contiguous to the premises on which the work or any part thereof is
being executed, or if any damage shall be done to the work while it is in
progress, from any cause whatever, or if any damage of any kind is
done to the plant material incorporated in the work, or if any
imperfections become apparent in it within twelve months of the grant
of a Certificate of Completion, final or otherwise, by the Site-In-Charge
or other competent authority, the Contractor shall make good the same
Page 23 of 60
at his own expense, or in default, the Site-In-Charge or other competent

authority may cause the same to be made good by other workmen, and
deduct the expenses (of which the certificate of the Site-In-Charge or
other competent authority shall be final) from any sums that may be due
or may thereafter become due to the Contractor, or from his security
deposit or the proceeds of sale thereof, or of a sufficient portion thereof.
The Contractor shall provide maintenance for the work for the above-
specified period of twelve months, and shall ensure that all works are
maintained in perfect condition.
19. Program of work The Contractor shall submit a revised Schedule & Chart detailing the
scheduled program of works and schedule of procurement of materials,
as per the time frame specified in this tender, and approved by the
Employer/ Landscape Architect/Architect. The said Schedule & Chart
shall be submitted subsequent to the acceptance of the tender and within
seven days of the final agreement made between the Employer and the
Contractor. The Schedule & Chart shall be considered part of the final
agreement, and shall be binding upon the Contractor.
The Schedule shall be revised and brought up-to-date every month and
copies of the same shall be forwarded to the Landscape
Architect/Employer. It is the Contractor's responsibility to see that these
schedules are adhered to. The Employer will not entertain any claim by
of the Contractor and Landscape Contractors on account of delay in
delivery of materials by the Employer.
20. Written order to After acceptance of the tender, the Site-In-Charge shall issue a written
commence work order to the successful tenderer to commence the work, and the
Contractor shall begin work at site within seven days of receiving such
order.
The Contractor shall enter upon or commence any portion of work only
with the written authority and instructions of the Site-In-Charge.
Without such instructions the Contractor shall have no claim to demand
for measurements of or payment for work done by him.
21. Review of progress The progress of works shall be reviewed periodically by the
Employer/Landscape Architect, as per the Schedule & Chart submitted
by the Contractor at the time of final agreement and revised
periodically.
22. Responsibility for delay In case the progress achieved falls short by more than 25 percent of the
cumulative program, the reasons for such shortfall shall be examined
and a record made thereof apportioning the responsibilities for the delay
between the Contractor and the Employer. This record should be signed
in full and dated both by the Site-In-Charge and the Contractor.
23. Settlement of dispute In case of dispute between the Site-In-Charge and the Contractor
regarding shortfall in regarding the responsibility for the shortfall in progress, the matter shall
progress be referred to the Landscape Architect who shall thereupon give
decision within one month of the date of receipt of reference. The
decision of the Landscape Architect shall be final and binding on the
Contractor and the Site-In-Charge.
24. Materials and All materials and workmanship shall, so far as procurable, be of the
workmanship respective kinds described in the schedule of quantities and/or
specification and in accordance with the Landscape Architect/Site-In-
Charge instructions. The Contractor shall, upon the request of the
Landscape Architect/Employer, furnish him with all invoices, accounts,
receipts, and other vouchers to prove that the materials comply
therewith.
All planting materials to be used on the work shall comply with the
requirements of the specifications in case of not confirming shall be
established as the best available in the market by the Landscape
Architect/Site-In-Charge on due verification before approving the same
Page 24 of 60
to be planted on site.
The Contractor shall be entirely responsible for the proper and efficient
carrying out of the work. The work shall be done in the best and most
workmen like manner. The availability of the best available planting
materials shall be inspected by the site-in-charge or his designated staff
from the source of procurement before being loaded for transport to the
site. The contractor shall be required to make arrangement for the visit
after he has identified the source for approval by Employer/Landscape
Architects or his representative on the site.
25. Samples of work The Contractor shall at his cost make all arrangements or shall provide
for all such facilities as the Site-In-Charger/Landscape Architect may
require for execution of the samples to such place or places as may be
directed the Site-In-Charge/Landscape Architect.
26. Drawings The details of the Landscape Areas are shown on the drawings attached
at the end of this document.
Figures of dimensions shall be followed in preference to scale

dimensions, and all dimensions and particulars shall be taken from the
actual work.
All drawings, tracings, photo prints, blue prints and writings

(except letters) are to be considered, by all parties concerned, to be
the sole property of the Landscape Architect, and they must be
returned to him on the completion of the work.
The drawings maintained in the site are to be carefully mounted on

boards of appropriate size and covered with a coat of approved varnish,
and should be protected from rain. They are to be protected from
ravages of termites, ants, silver fish and other insects.
The Contract shall remain in the custody of the Employer, and a

duplicate copy of the Contract shall remain in the custody of the
Landscape Architect. The Contractor, on the signing hereof, shall be
furnished by the Landscape Architect/Employer free of cost with a copy
of the priced Bill of Quantities, one copy of each of the said Drawings
and of the Specification and one copy of all further drawings issued
during the progress of the work. The Contractor shall keep one copy of
all drawings on the works, and the Landscape Architect/Architect or his
representative shall at all reasonable times have access to the same.
Before the issue of the Final Certificate of the Contractor, he shall
forthwith return to the Landscape Architect/Site-In-Charge all drawings
and specifications
27. Adherence to time The whole work, including extra and additional items, is to be
schedule completed as per the work schedule and the Contractor will be required,
if necessary, to work overtime to fulfill the Site-In-Charge/Landscape
Architects instructions to complete the work.
The completion period, as stated in the Contract, shall be strictly

adhered to by the Contractor, and shall be reckoned from the date on
which the order to commence the work is issued to the Contractor in
writing by the Employer. It is the Contractors responsibility to
maintain the rate of progress as stipulated in the periodic Schedule &
charts.
28. Date of commencement The Contractor shall be allowed admittance to the site on the Date of
& completion Commencement as per instruction by the site-in-charge, and he shall
thereupon and forthwith begin the works and shall regularly proceed
with the completion as per the schedule mutually agreed upon between
the site-in-charge and the contractor. The Completion date shall be
binding on the contractor.
Page 25 of 60
29. Setting out work The Contractor shall set out the works and shall be responsible for the
true and perfect setting out of the same and for the correctness of the
position, levels, dimensions and alignment of all parts thereof in
accordance with the drawing, If at any time any error in this respect
shall appear during the progress of the works, the Contractor shall, at
his own expense, rectify such error as required, to the satisfaction of the
Site-In-Charge/Landscape Architect.
The Contractor shall have to clear the site as directed before the work is
commenced, without any extra cost.
30. Grant of extension of If the Contractor shall desire an extension of the time for completion of
time the work on the ground of his having been unavoidably hindered in its
execution or on any other ground, he shall apply in writing to the Site-
In-Charge before the expiration of the period stipulated in the tender or
before the expiration of thirty days from the date on which he was
hindered as aforesaid or on which the cause for asking for extension
occurred, whichever is earlier; and the Site-In-Charge or other
competent authority may, if in his opinion there are reasonable grounds
for granting an extension, grant such extension as he thinks necessary
or proper. The decision of such competent authority in this matter shall
be final.
The time limit for completion of the work shall be extended

commensurate with its increase in cost occasioned by alterations or
additions, and the certificate of the Site-In-Charge or other competent
authority as to such proportion shall be conclusive.
If the delay is attributable to reasons beyond the control of the

Contractor, requisite extension of time shall be granted by the Site-In-
Charge in after obtaining the approval of his higher authorities
wherever necessary.
31. Shortfall in progress To the extent the shortfall is assessed, as due to the delay on the part of
made up subsequently the Contractor, a notice shall be issued to him by the Site-In-Charge and
penalty shall be levied..
32. Penalty for delay When the shortfall in the progress of work is determined to be due to
delay on the part of the Contractor, he shall be held to be responsible
for the same and shall be liable to pay penalty. In respect of the shortfall
in progress, assessed as due to the delay on part of the Contractor the
Contractor shall be liable to pay as penalty an amount of Rs.5000/-
(Rupees Five Thousand only) per day, up to a maximum amount of 2 %
in contract sum, after which the Employer reserves the right to
terminate the Contract.
NOTE: If the Site-In-Charge considers it necessary, he shall also be

entitled to take action.
In the case of any failure by the Contractor to pay such penalty, the
Site-In-Charge or other competent authority may rectify or remove, and
re-execute the work or remove and replace the materials or articles
complained of, as the case may be, at the risk and expense in all
respects of the Contractor.
33. Action when whole of In any case in which under any clause or clauses of this Contract, the
Security Deposit is Contractor shall have rendered himself liable to pay compensation
forfeited and/or penalty amounting to the whole of his Security Deposit
including the amount deducted in installments from his bills as Further
Security Deposit, the Site-In-Charge, on behalf of the Employer, shall
have power to adopt any of the following courses as he may deem best
suited in the interest of MAHINDRA WORLD CITY (JAIPUR)
LTD.,
Page 26 of 60
34. Rescission of Contract To rescind the Contract (of which rescission notice in writing to the
and Forfeiture of Contractor under the hand of the Site-In-Charge shall be conclusive
security deposit evidence), without prejudice to the right of MAHINDRA WORLD
CITY (JAIPUR) LTD., to recover any loss from the Contractor. In
that case, the Security Deposit of the Contractor, including whole or
part of the lump sum deposited by him and also the amount deducted
from his bills as Further Security Deposit, shall stand forfeited and be
absolutely at the disposal of MAHINDRA WORLD CITY
(JAIPUR) LTD., Debiting cost of labor and materials supplied
To employ labour paid by the MAHINDRA WORLD CITY

(JAIPUR) LTD., And to supply materials to carry out the work or any
part of the work, debiting the Contractor with the cost of the labor and
the price of the materials (as to the correctness of which cost and price
the certificate of the Site-In-Charge shall be final and conclusive
against the Contractor) and crediting him with the value of the work
done, in all respects in the same manner and at the same rates as if it
had been carried out by the Contractor under terms of this Contract,
and in that case the certificate of the Site-In-Charge as to the value of
the work done shall be final and conclusive against the Contractor.
35. Recovery of extra cost on To measure up the work of the Contractor and to take such part thereof
unexecuted work as is remaining unexecuted out of his hands, and to give it to another
Contractor to complete it, in which case any expenses which may be
incurred in excess of the sum which would have been paid to the
original Contractor, if the whole work had been executed by him (as to
the amount of which excess expenses, the certificate in writing of the
Site-In-Charge shall be final and conclusive), shall be borne and paid
by the original Contractor and shall be deducted from any money due
to him MAHINDRA WORLD CITY (JAIPUR) LTD., Under this
Contract or otherwise or from his security deposit or the proceeds of
sale thereof, or a sufficient part thereof.
36. Action against If the Contractor does not maintain the rate of the progress as required
unsatisfactory progress and if the progress of any particular portion of work is unsatisfactory
even after taking action. The Site-In-Charge shall be entitled to take
action in order to maintain the rate of progress, after giving the
Contractor ten days notice in writing, whereupon the Contractor will
have no claim for any compensation for any loss sustained by him
owing to such actions.
37. No compensation for In the event of any of the above courses being adopted by the Site-In-
loss sustained on Charge, the Contractor shall have no claim to compensation for any loss
advance action sustained by him by reason of his having purchased or procured any
materials, or entered into any engagements, or made any advances on
account of or with a view to the execution of the work or the
performance of the Contract. And in case the Contract shall be
rescinded under the provision aforesaid, the Contractor shall not be
entitled to recover or be paid any sum for any work thereof actually
performed by him under this Contract, unless and until the Site-In-
Charge shall have certified in writing the performance of such work and
the amount payable in respect thereof, and he shall only be entitled to
be paid the amount so certified.
38. Contractor to remain In any case in which any of the powers conferred upon the Site-In-
liable to pay Charge hereof shall have become exercisable and the same shall not
compensation if action have been exercised, the non-exercise thereof shall not constitute a
is not taken waiver of any of the conditions thereof, and such powers shall be
exercisable in the event of any future case of default by the Contractor
for which under any clause thereof he is declared liable to pay
compensation or penalty amounting to the whole of his Security
Deposit, and liability of the Contractor for past and present
compensation or penalty shall remain unaffected.
39. Sub-standard work If at any time before the security deposit is refunded to the Contractor,
it shall appear to the Site-In-Charge or other competent authority, that
any work has been executed with unsound, imperfect or unskillful
Page 27 of 60
workmanship or with materials of inferior quality, or that any materials

or articles provided by the Contractor for the execution of the work are
unsound, or of a quality inferior to that contracted for or are otherwise
not in accordance with the Contract, it shall be lawful for the Site-In-
Charge or other competent authority to intimate this fact in writing to
the Contractor, who shall then be bound forthwith to rectify, or remove
and reconstruct the work so specified in whole or in part as the case
may require, or if so required, shall remove the materials or articles at
his own charge and cost, within such reasonable time as may be
specified in the order.
40. Acceptance of sub- Should the Site-In-Charge or other competent authority for any valid
standard work reasons consider that any such inferior work or materials as described
above is to be accepted or made use of, it shall be within his discretion
to accept the same at such reduced rates he may fix thereof.
The decision of the Site-In-Charge, regarding the quantum of reduction

as well as justification thereof in respect of rates for sub-standard work
which may be decided to be accepted, will be final and would not be
open to arbitration.
41. Settlement of disputes If any dispute or difference of any kind whatsoever were to arise
between the Site-In-Charge and the Contractor regarding the following
matters, namely:
* The meaning of the specifications designs, drawings and

instructions herein before mentioned;
* The quality of workmanship or materials used on the work; and
* Any other question, claim, right, matter, thing whatsoever, in any
way arising out of or relating to the Contract, design, drawings,
specification estimates, instructions, or orders, or those conditions
or failure to execute the same whether arising during the progress
of the work, or after the complete termination or abandonment
thereof,
The dispute shall be referred to the Landscape Architect who has

jurisdiction over the work specified in the Contract. The Landscape
Architect shall, within a period of ninety days from the date of being
requested by the Contractor to do so, give written notice of his decision
to the Contractor.
42. Landscape Architects The decision of the Landscape Architect in respect of every dispute or
decision final difference so referred shall be final and binding upon the Contractor.
The said decision shall forthwith be given effect to and the Contractor
shall proceed with the execution of the work with all due diligence.
43. Time limits for Under no circumstances whatever shall the Contractor be entitled to any
unforeseen claims compensation from MAHINDRA WORLD CITY (JAIPUR) LTD.,
on any account unless the Contractor shall have submitted a claim in
writing to the Site-In-Charge or other competent authority within thirty
days of the cause of such claim occurring.
44. Measurement/Assessme The Landscape Architect/Site-In-Charge may, from time to time,
nt of work intimate to the Contractor that he requires the works to be measured,
and the Contractor shall forthwith assist or send a qualified agent to
assist the Site-In-Charge/Landscape Architect (or their representative)
in taking such measurements and calculations, and to furnish all
particulars or to give all assistance required by either of them. The
Contractor shall agree to all such measurements recorded on the spot.
Before taking any measurements of the works, the Site-In-

Charge/Landscape Architect shall give reasonable notice to the
Contractor and contractor shall make arrangement of manpower,
measuring tools or if any either required
45. Non-attendance of Should the Contractor not attend or neglect or omit to send such Agent
within a week of the specified time period, the measurement taken by
Page 28 of 60
Contractor the Landscape Architect/Employer or approved by him shall be taken

to be the correct measurement of the works, and shall be binding on the
Contractor, and the Contractor shall have no right to dispute the same.
46. Change in classification Once the measurements mentioning the classification of any works is
of works accepted recorded in the measurement book and the same is signed by the
Contractor or his authorized agent in token of acceptance, no request
for reclassification by the Contractor shall be entertained.
47. Submission of bills A bill shall be submitted by the Contractor on or before the 5th of each
month for all items of work executed in the previous month.
All bills shall be prepared in the prescribed printed or typed form in

quadruplicate along with same indicated clearly on the copy of the
drawing fpr physical location details of the jobwork and handed over to
the Site-In-Charge in charge and acknowledgment obtained.
The charges to be made in the bills shall always be entered at the rates
specified in the tender, in full or in part as the case may be. In the case
of any extra work ordered in pursuance of these conditions, and not
mentioned or provided for in the tender, the charges in the bills shall be
entered at the rates herein provided for such work.
One copy of the passed bill shall be given to the Contractor without
any charge.
48. Scrutiny of bills The details furnished by the Contractor in the bill should be completely
scrutinized and the said work should be checked to be in accordance
with the measurements recorded on the spot. The countersignature of
the Contractor or his agent in the Measurement Book and drawing shall
be sufficient proof as to the correctness of measurements, and shall be
binding on the Contractor in all respects.
49. Non-submission of bills If the Contractor does not submit the bills within the prescribed date,
the Site-In-Charge shall deputize a subordinate to measure up the said
work. The countersignature of the Contractor shall be obtained in the
Measurement Book concerned, with reference to which the bill may be
prepared by the Site-In-Charge.
50. Payment of bills The Contractors shall be paid by the Employer, from time to time, by
installments under Interim Certificates to be issued by the Site-In-
Certificate and Charge/Landscape Architect to the Contractor, on account of the works
payments executed, when in the opinion of the Landscape Architect/Site-In-
Charge work to the approximate value named in the Appendix as
Value of work for Interim Certificates (or less at the reasonable
discretion of the Site-In-Charge/Landscape Architect) has been
executed in accordance with this Contract, subject, however, to a
retention of the percentage of such value named in the Appendix hereto
as "Retention Percentage for Interim certificates.
The Contractor will be entitled to be paid in the Interim Certificate an

amount calculated up to 75% of the actual cost of material delivered at
the site by the Contractor for incorporation in the work and which, in
the opinion of the Landscape Architect/Site-In-Charge, shall be non-
perishable and duly insured.
The Contractor shall be entitled to the payment of the Final balance in

accordance with the Final Certificate to be issued in writing by the Site-
In-Charge/Landscape Architect at the expiration of the period referred
to as the Defects Liability Period in the Appendix hereto, or as soon
after the expiration of such period as the works shall have been finally
completed and all defects made good according to the true intent and
meaning hereof, whichever shall last happen, provided always that the
issue by the Site-In-Charge/Landscape Architect of any Certificate
during the progress of the works or at or after their completion shall not
Page 29 of 60
relieve the Contractor of his liability in cases of fraud, dishonesty, or

fraudulent concealment relating to the works or materials or to any
matter dealt with in the certificate, and in case of all defects and
insufficiencies in the works or materials which a reasonable
examination would not have disclosed.
No certificate of the Site-In-Charge/Landscape Architect shall of itself

be conclusive evidence that any work or materials to which it relates are
in accordance with the Contract.
The Site-In-Charge/Landscape Architect shall have power to withhold

any certificate if the works or any parts thereof are not being carried out
to his satisfaction.
The Site-In-Charge/Landscape Architect may, by any certificate, make

any correction in any previous certificate which shall have been issued
by him.
Payments upon the Site-In-Charge/Landscape Architects Certificate

shall be made within the periods named in the Appendix as Period for
honoring of Certificates and after such certificates have been delivered
to the Employer.
No payment shall be made before the issue of virtual completion

certificate by the Site-In-Charge for the selected stretch of the
landscape works and hence submission of the bills thereof.
51. Recovery of excess Whenever it is noticed that excess payments have been made to the
payments based on Contractor based on excess measurements recorded by his subordinate
excess measurements in the measurement book and countersigned by the Contractor or his
and action against duly authorized agent, action shall be taken to recover the excess
contractor payments together with interest immediately. Action may also be taken
to remove the name of the Contractor from approved list of contractors
and so to black-list the firm.
52. Payment of intermediate All such intermediate payments shall be regarded as payments by way
certificates to be of advance against the final payments only, and not as payments for
regarded as advances works actually done and completed, and shall not preclude the Site-In-
Charge or other competent authority from requiring any bad, unsound,
imperfect or unskillful work to be removed or taken away and
reconstructed or re-erected, nor shall any such payment be considered
as an admission of the due performance of the Contract or any part
thereof in any respect of the accruing of any claim, nor shall it
conclude, determine or affect in any other way the powers of the Site-
In-Charge or other competent authority as to the final settlement and
adjustment of the accounts, or otherwise or in any other way vary or
affect the Contract.
53. Submission of final bill The final bill shall be submitted by the Contractor within one month of
and its settlement the date of actual completion of the work in all respects. His claims
shall be settled (except those under dispute) within Two months
thereafter in respect of works.
54. Payment of lump-sums When the estimate on which a tender is made includes lump-sums in
in estimate respect of parts of the works, the Contractor shall be entitled to payment
in respect of the items of the work involved or the part of the work in
question at the same rates as are payable under this Contract for each
item, or if the part of the work in question is not, in the opinion of the
Site-In-Charge or other competent authority, capable of measurement,
the Site-In-Charge or other competent authority may at his discretion
pay the lump sum amount entered in the estimate, and the certificate in
writing of the Site-In-Charge or other competent authority shall be final
and conclusive against the Contractor with regard to any sum or sums
Page 30 of 60
payable to him under the provisions of this clause.
It will be necessary for the Contractor to produce a statement of

expenditure incurred by him for such items of work, and the amount
payable should be limited to the provisions made in the estimate, and
the Site-In-Charge should satisfy himself about the correctness of the
statement of expenditure furnished by the Contractor.
In the case of lump sum items, it is understood that the Contractor has
taken into consideration all details/drawings provided before quoting.
All queries regarding clarification should be made before quoting. The
tenderer shall not be entitled to any claim on the lump-sum items.
55. Issue of final certificate On completion of the work, the Contractor shall report in writing to the
Site-In-Charge the completion of such work, and the Site-In-Charge
Certificate of virtual shall issue a certificate of Virtual Completion stating in writing that the
completion work has been so completed. The Defects Liability Period shall
commence from the date of such certificate.
The works shall not be considered as completed until the Site-In-

Charge/Architect has certified in writing that they have been virtually
completed
56. Conditions However, no such certificate shall be given nor shall the work be
considered to be complete until the Contractor shall have removed from
the premises on which the work shall have been executed all surplus
materials and rubbish, and shall have cleaned thoroughly all finished
surfaces, in or upon which the work has been executed, nor until the
works shall have been measured by the Site-In-Charge or other
competent authority, or where the measurements have been taken by his
subordinates until they have received the approval of the Site-In-Charge
or other competent authority, the said measurements being binding and
conclusive against the Contractor. If the Contractor shall fail to comply
with the requirements of this clause as to the removal of scaffolding,
surplus materials and rubbish, and cleaning the premises, on or before
the date fixed for the completion of the work, the Site-In-Charge or
other competent authority may, at the expense of the Contractor,
remove such surplus materials and rubbish and dispose of the same as
he thinks fit and clean off such dirt etc. as aforesaid; and Contractor
shall be liable to pay the amount of all expenses so incurred, but shall
have no claim in respect of any such surplus materials as aforesaid
except for any sum actually realized by the sale thereof.
57. Termination of If the Contractor, being an individual or a firm, commit any Act of
contract by employer Insolvency or shall be adjudged as Insolvent or, being an incorporated
company, shall have an order for compulsory winding up made against
it, or pass an effective resolution for winding up voluntarily or subject
to the supervision of the court and of the Official Assignee of the
Liquidator in such acts of insolvency, or on winding up shall be unable
within seven days after notice to him requiring him to do so, to show to
the reasonable satisfaction of the Landscape
Architect/Architect/Employer that he is able to carry out and fulfill the
Contract, and to give security therefor, if so required by the Landscape
Architect/Architect or the Employer, or if the Contractor (whether an
individual, Firm or Incorporated Company) shall suffer execution to be
issued, or shall suffer any payment under this Contract to be attached by
or on behalf of any of the creditors of the Contractor, or shall assign or
sublet this Contract without the consent in writing of the Architect first
obtained, or shall charge or encumber this Contract or any payments
due or which may become due to the Contractor thereunder, or if the
Landscape Architect/Architect shall certify in writing to the Employer
that the Contractor:
a) Has abandoned the Contract, or
Page 31 of 60
b) Has failed to commence the works, or has without any lawful

excuse under these conditions suspended the progress of the
works, or
c) Has failed to proceed with the works with such due diligence
and failed to make such due progress as would enable the
works to be completed within the time agreed upon, or
d) Has failed to remove rejected materials from the site or to pull
down and replace rejected work upon receiving from the
Landscape Architect/Employer written notice that the said
materials or work were condemned and rejected by the
Landscape Architect/Employer under these conditions, or
e) Has neglected or failed persistently to observe and perform all
or any of the acts, matters or things by this Contract to be
observed and performed by the Contractor, after written
notice shall have been given to the Contractor requiring the
Contractor to observe or perform the same, or
f) Has to the detriment of good workmanship, or in defiance of
the Site-In-Charge/Landscape Architects instructions to the
contrary, sublet any part of the Contract,
Then and in any of the said cases, the Employer with the written
recommendation of the Landscape Architect may, notwithstanding any
previous waiver, after giving seven days notice in writing to the
Contractor, terminate the Contract.
Further, the Employer or his agent or his servants, may enter upon and
take possession of the works and all plant, tools, scaffoldings, sheds,
machinery, and other power utensils and materials lying upon the
premises or the adjoining lands or roads, and use the same as his own
property or may employ the same by means of his own servants and
workmen in carrying out and completing the works, or by employing
any other Contractors or other person or persons to complete the works,
and the Contractor shall not in any way interrupt or do any act, matter
or thing to prevent or hinder such other Contractor or other person or
persons employed for completing and finishing or using the materials
and plant for the works. Upon completion, or as soon thereafter as
convenient, the Landscape Architect/Employer shall give a notice in
writing to the Contractor to remove his surplus materials and plant, and
should the Contractor fail to do so the Employer shall sell the same by
public auction, and shall give credit to the Contractor for the amount
realized.
58. Contractor to The Contractor shall give all necessary personal supervision during the
superintend work execution of the works, and active supervision on the works as long
thereafter as the Landscape Architect/Site-In-Charge may consider
necessary, until the expiration of the "Defects Liability Period" stated in
the Appendix hereto.
59. Contractor or The Contractor shall, at all times during the usual working hours, and at
responsible agent to be all other times at which reasonable notice of the intention of the Site-In-
present Charge or other competent authority or his subordinate to visit the work
shall have been given to the Contractor, either himself be present to
receive orders and instructions, or have a responsible agent, duly
accredited in writing, present for the purpose. Orders given to the
Contractors duly authorized agent shall be considered to have the same
force and effect as if they had been given to the Contractor himself.
60. Employment of The Contractor shall employ the following technical staff during
technical staff execution of this work:-
i) Graduate Horticulturist as Site-In-Charge

ii) In addition, the Contractor shall employ different types of
Page 32 of 60
such technical personnel as may be directed by the Site-In-

Charge to ensure efficient execution of work.
The technical staff so employed should be available at site, whenever

required by Site-In-Charge, to take instructions.
If the Contractor fails to employ the technical staff as aforesaid, he shall

be liable to pay a sum of Rs.25000/- (Rupees Five Thousand Five
Hundred only) for each month of default in the case of Graduate Site-
In-Charges and Rs.10000/- (Rupees Three thousand Five Hundred only)
for each month of default in case of Diploma Holders.
If the Contractor himself possesses the required qualification and is

available at the site for receiving instructions from the Site-In-Charge
or other competent authority as per Clause 23.b. above, it will not be
necessary for the technical staff to be available at site for receiving
instructions.
61. Contractors services at The Contractor shall place at the disposal of the Site-In-
the disposal of Charge/Landscape Architect the service and advice of himself and his
Landscape Architect firm, and their staff of Site-In-Charges, managers, buyers, or materials,
foremen of trades or other skilled persons employed by him or them, for
the conduct of the work comprised in this Contract.
62. Work open to inspection The Landscape Architect (and his representative) and the Employer
shall, at all reasonable times, have free access to the work and/or to the
workshops factories, or other places where materials are lying or from
which they are being obtained, and the Contractor shall give every
facility to the Site-In-Charge/Landscape Architect necessary for
inspections and examination and test of the materials and workmanship.
All works under or in course of execution or executed in pursuance of

the Contract shall at all times be open to the inspection and supervision
of the Site-In-Charge or other competent authority and his subordinates.
The Contractor shall at all reasonable times give access to workmen

employed by local or other authorities or any men employed on the
buildings, and shall provide such parties with proper, sufficient and if
required special scaffoldings, hoists and ladders, and provide them with
water and lighting and leave to make holes, grooves, chases, cutting
etc., in any work where directed by the Site-In-Charge/Landscape
Architect,
No person other than those authorized by the Architect/Landscape

Architect shall be allowed on the works at any time.
63. Notice to be given The Contractor shall give not less than five days notice in writing to the
before work is covered Site-In-Charge before covering up or otherwise placing beyond the
up reach of measurement any work, in order that the same may be
measured, and correct dimensions thereof taken before the same is so
covered up or placed beyond the reach of measurement; and shall not
cover up or place beyond the reach of measurement any work without
the consent in writing of the Site-In-Charge or other competent
authority or his subordinate in charge of work. If any work shall be
covered up or placed beyond the reach of measurement without such
notice having been given or consent obtained, the same shall be
uncovered at the Contractors expense, and in default thereof no
payment or allowance shall be made for such work or for the materials
with which the same was executed.
64. Work not to be sublet The whole of the works included in the Contract shall be executed by
the Contractor, and the Contractor shall not directly or indirectly
transfer, assign or sublet the Contract or any part share thereof or
interest therein, without the written consent of Landscape
Architect/Employer; and no undertaking shall relieve the Contractor
Page 33 of 60
from the full and entire responsibility of the Contract or from active
supervision of the works during their progress.
The Contract shall not be assigned or sublet by the Contractor.

However, any specific portion of the work which is of a specialized
nature, and normally not executable by a general contractor, could be
got done by the specialized agencies which are executing such works,
after obtaining the specific approval of the Site-In-Charge in writing in
each case. Such consent to sublet the work, if given, shall not relieve
the Contractor from any liability or obligation under the Contract and
he shall be responsible for the acts, defaults and neglects of any
Landscape Contractor or his agents, servants and workmen as fully as if
they were the acts, defaults or neglects of the Contractor, his agents,
servants or workmen.
65. Consequences of If any bribe, gratuity, gift, loan, perquisite, reward or advantage,
bribing etc. by pecuniary or otherwise, shall either directly or indirectly be given,
contractor and penalty promised or offered by the Contractor or any of his servants or agents to
any public officer or person in the employ of MAHINDRA WORLD
CITY (JAIPUR) LTD., in any way relating to his office or
employment, or if any such officer or person shall become in any way
directly or indirectly interested in the Contract, the Site-In-Charge or
other competent authority may determine that the Security Deposit shall
thereupon stand forfeited and be absolutely at the disposal of
MAHINDRA WORLD CITY (JAIPUR) LTD., and the same
consequences shall ensure as if the Contract had been rescinded hereof,
and in addition, the Contractor shall not be entitled to recover or be paid
for any work actually performed under Contract.
66. Contractor liable for The Contractor shall protect from injury/damages from any cause
damages in work area whatsoever all work and supply to any other requisite protection for the
whole work executed by him or special damage caused must be made
good by the Contractor at his own expense.
All Landscape works, trees, shrubs, plants, lawns apart from the
features present within or outside the plantation area shall be
maintained, and kept free from damage due to operations in connection
with the work.
The Contractor shall make his own arrangements for prevention and
appropriate measure for protection of the plantation materials from the
cattle and wild animals at his own cost.
Should the work be suspended by reason of rain, strike, lockouts or any

other disturbing cause, the Contractor shall take all precautions
necessary for the protection of the work at his own expense, and shall
make good any damage arising from any of the causes.
Compensation for all damages done by Contractor or his men whether

in or beyond the limits of MAHINDRA WORLD CITY (JAIPUR)
LTD., property, including any damage caused by spreading of fire,
shall be estimated by the Site-In-Charge, and the estimate of the Site-
In-Charge, subject to the decision of the Landscape Architect on appeal,
shall be final. The Contractor shall be bound to pay the amount of the
assessed compensation on demand, failing which the same will be
recovered from the Contractor as damages in the manner herein
prescribed or deducted by the Site-In-Charge or other competent
authority from any sums that may be due or become due from
MAHINDRA WORLD CITY (JAIPUR) LTD., to the Contractor
under this Contract or otherwise.
67. Insurance in respect of The Contractor shall be responsible for all injury to persons, animals or
damages to persons and things, and damage to structural and decorative works and damage to
neighboring property, which may arise from the operation or neglect of
Page 34 of 60
property himself or of any nominated Landscape Contractors or their employees,

whether such injury or damage arise from carelessness, accident or any
other cause which is in any way connected with the carrying out of this
Contract. This clause shall be held to include, inter alia, any damage to
buildings and works forming the subject of this Contract by frost or
other inclemency of weather. The Contractor shall indemnify the
Employer and hold him harmless in respect of all and any expense
arising from any such injury or damage to persons or property as
aforesaid, and also in respect of any claim made in respect of injury or
damage under any Act of Government or otherwise, and also in respect
of any award of compensation or damages consequent upon such claim.
The Contractor shall reinstate all damage to property of every sort

mentioned in this clause, so as to deliver up the whole of the contract
works complete and perfect in every respect, and so as to make good or
otherwise satisfy all claims for damage to the property of third parties.
The Contractor shall indemnify the Employer against all claims which
may be made against the Employer by any member of the public or
other third party, in respect of anything which may arise in connection
to the works or in consequence thereof. The Contractor shall, at his own
expense, arrange to effect and maintain, until the virtual completion of
the Contract, a policy of Insurance against such risks, in the joint names
of the Employer and the Contractor, with an approved office; and
deposit such policy or policies with the Architect/Employer from time
to time during the currency of this Contract.
The Contractor shall similarly indemnify the Employer against all

claims which may be made upon the Employer, whether under the
Workmen's Compensation Act or any other statute in force during the
currency of this Contract, or at common Law in respect of any
employee of the Contractor or any Landscape Contractor and shall at
his own expense effect and maintain until the virtual completion of the
Contract, with an approved office, a policy of Insurance in the joint
names of the Employer and the Contractor against such risks, and
deposit such policy or policies with Architect/Employer from time to
time during the currency of the Contract.
The Contractor shall be responsible for anything which may be

excluded from the Insurance policies above referred to, and also for all
other damages to any property arising out of and incidental to the
negligent or defective carrying out of this Contract. He shall also
indemnify the Employer in respect of any costs, charges or expenses
arising out of any claim or proceeding, and also in respect of any award
of or compensation of damage arising therefrom.
The Employer, with the concurrence of the Architect, shall be at liberty

and is hereby empowered to deduct the amount of any damage,
compensation, costs, charges and expense arising or accruing from or in
respect of any such claims or damage, from any sum or sums due or to
become due to the Contractor.
68. Prevention of fire The Contractor shall not set fire to any standing jungle, trees,
brushwood or grass without a written permit from MAHINDRA
WORLD CITY (JAIPUR) LTD.,
When such permit is given, and also in all cases when destroying cut or
dug up trees, brushwood, grass, etc., by fire, the Contractor shall take
necessary measures to prevent such fire spreading to or otherwise
damaging surrounding property.
69. Fire insurance The Contractor shall, at the time of signing the Contract, insure the
works, and keep them insured until the virtual completion of the
Page 35 of 60
Contract, against loss or damage by fire, in an office to be approved by

the Landscape Architect, in the joint names of the Employer and
Contractor (the name of the former being placed first in the policy), for
the full amount of the Contract and for any further sum if called upon to
do so by the Landscape Architect/Employer, the premium of such
further sum being allowed to the Contractor as an authorized extra.
Such policy shall cover the property of the Employer only, fees for
assessing the claim and in connection with his services generally
therein, and shall not cover any property of the Contractor or of any
Landscape Contractor or employee. The Contractor shall deposit the
policy and receipts for the premiums with the Employer within twenty-
one days from the date of signing the Contract, unless otherwise
instructed by the Landscape Architect. In default of the Contractor
insuring as provided above, the Employer may so insure and may
deduct the premiums paid from any money due or which may become
due to the Contractor. The Contractor shall, as soon as the claim under
the policy is settled, or the work reinstated by the Insurance Office,
should they elect to do so, proceed with all due diligence with the
completion of the works in the same manner as though the fire had not
occurred and in all respect under the same conditions of Contract.
In the case of rebuilding or reinstatement after fire, the Contractor shall

be entitled to such extension of time for compensation as the Landscape
Architect/Architect deems fit.
The Contractor shall bear the expenses of defending any action or other
legal proceedings that may be brought by any person for injury
sustained by him owing to neglect of precautions to prevent the spread
of fire and shall pay any damages and cost that may be awarded by the
court in consequence.
70. Contractor to provide The Contractor shall provide everything necessary for the proper
everything necessary execution of the works according the intent and meaning of the
Drawings, Schedule of Quantities and Specification taken together,
whether the same may or may not be particularly shown or described
therein, provided that the same can reasonably be inferred therefrom.
71. Materials The Contractor shall supply at his own cost all materials (except such
special materials, if any, as may in accordance with the Contract be
supplied from by MAHINDRA WORLD CITY (JAIPUR) LTD.,
plant, tools, appliances, implements, ladders, cordage, tackle,
scaffolding and temporary works requisite for the proper execution of
the work, whether in the original, altered or substituted form, and
whether included in the specifications or other documents forming part
of the Contract or referred to in these conditions or not, and which may
be necessary for the purpose of satisfying or complying with the
requirements of the Site-In-Charge or other competent authority as to
any matter as to which under these conditions he is entitled to be
satisfied, required together with carriage therefore, to and from the
work. The Contractor shall also supply without charge the requisite
numbers of persons with the means and materials necessary for the
purpose of setting out works, executing the work, and counting,
weighing and assisting in the measurement or examination, at any time
and from time to time, of the work or the materials.
i) Theodolites, leveling instruments, prismatic compass, chain,

steel and metallic tapes and all other surveying instruments,
found necessary on the work for the due performance of this
Contract as instructed by Site-In-Charge/Landscape Architect,
shall be provided by the Contractor.
72. Services The Contractor shall provide such temporary road or roads on the site
as may be necessary for the proper performances of the Contract and
Page 36 of 60
for his own conveyance and also for the Landscape Contractors of the
Employer. Upon completion such roads shall be broken up and leveled,
where so required by the drawings, unless Site-In-Charge/Landscape
Architect shall otherwise direct.
The Contractor shall provide and maintain proper sheds for the storage
and protection of materials etc., and other work that may be executed
on the site, including the tools and materials that may be used for
execution on the site, including the tools and materials of Landscape
Contractors, and remove same on completion. Sheds for storage of
cement should be waterproof & lockable, and are to have floors raised
from the ground, and shall be open for inspection whenever required by
the Site-In-Charge/Landscape Architect, and shall be moisture-
free/water-proof and the same shall be removed after completion of
work as stipulated.
The Contractor shall provide at his own cost all artificial light required
for the work and to enable the Contractors and Landscape Contractors
to complete the work in specified time. The Contractor shall arrange for
alternate power supply by way of diesel generator set to avoid
interruption of work during power outages.
The Contractor shall execute any temporary plumbing that may be

required, and pay all fees and charges.
The Contractor shall make provision for water supply and sanitary
arrangements for his employees, and keep the same in a clean and
sanitary condition to the satisfaction of the public health authorities, and
shall make good all works disturbed by these conveniences.
73. Security and safety The Contractor shall provide all persons working at site with helmets,
safety goggles, safety belts, and such other equipment, for ensuring
safety from injury.
The Contractor, from the time of being placed in possession of the site,
shall provide safety & security for watching, lighting and protecting the
work, the site and surrounding property by day, by night, on Sundays or
other holidays, at no extra cost to the Employer.
The Contractor shall provide any necessary temporary enclosures,

gates, entrances etc., for the protection of the work and materials, and
for altering and adopting same as may be required, and remove the
same at completion of the works and make good all works disturbed.
The Contractor shall display all danger signs, contains notices at the site
to notify all about the safety aspects.
The Contractor shall provide all necessary fencing and lights required
to protect the public from accident
74. Penalty for default If the Contractor is in default ,the same may be provided by the Site-In-
Charge or other competent authority at the expense of the Contractor,
and the expenses may be deducted from any money due to the
Contractor under this Contract or from his Security Deposit or the
proceeds of sale thereof, or of a sufficient portion thereof.
If the Contractor is in default ,he shall be bound to bear the expense of

defense of every suit, action or other legal proceedings, that may be
brought by any person for any injury sustained owing to neglect of the
above precautions, and to pay any damages and cost which may be
awarded in any suit, action or proceedings to any person, or which may
with the consent of the Contractor be paid for compromising any claim
Page 37 of 60
by any such person.

75. Authorities notices and The Contractor shall conform to the provisions of any Act of
patents Legislature relating to the woks, and of the Regulations and Bye-laws
of any Authority, and shall before making any variations from the
drawings or specification that may be necessitated by so conforming,
give the Landscape Architect/Architect/Employer written notice,
specifying the variation proposed to be made and the reason for making
it, and apply for instructions thereon. In case the Contractor shall not
within ten days receive such instruction he shall proceed with the work,
conforming to the provisions, regulations, or bye-laws in question, and
any variation so necessitated .The Contractor shall bring to the attention
of the Landscape Architect/Employer all notices required by the said
Acts, Regulations or Bye-laws to be given to any Authority and pay to
such authority, or to any Public Office, all fees that may be properly
chargeable in respect of the works, and lodge the receipts with the
Landscape Architect/Employer.
The Contractor shall indemnify the Employer against all claims in

respect to patent rights, and shall defend all actions arising from such
claims, and shall himself pay all royalties, license fees, damage, costs
and charges of all and every sort that may be legally incurred in respect
thereof.
76. Quarry fees All quarry fees, royalties, octroi dues levied by the State Government or
any local body or authority, and ground rent, if any, charged by the
Site-In-Charge for stacking materials, should be paid by the Contractor.
77. Apprentice act The Contractors shall comply with the provisions of the Apprentice Act
1961, and Rules and Orders issued thereunder from time to time. If he
fails to do so, his failure will be a breach of Contract, and the Employer
may at his discretion cancel the Contract. The Contractor shall also be
liable for any pecuniary liability arising on account of any violation by
him of the provisions of the Act.
78. Employment of labor Fair wages: The Contractor shall pay fair and reasonable wages, which
shall not be less than the minimum wages fixed by Government from
time to time, to the workmen employed by him in the Contract
undertaken by him. In the event of any dispute arising between the
Contractor and his workmen on the ground that the wages paid are not
fair and reasonable, the dispute shall be referred without delay to the
Site-In-Charge or other competent authority, who shall decide the same.
The decision shall not in any way affect the conditions in the Contract
regarding the payment to be made by MAHINDRA WORLD CITY
(JAIPUR) LTD,, at the agreed tender rates.
Work on notified holiday: No work shall be done on any notified

holiday without the sanction in writing of the Site-In-Charge or other
competent authority.
Labor from nearest exchange: The Contractor should as far as

possible obtain his requirement of labor, skilled and unskilled, from the
nearest Employment Exchange. The Contractor should give preference
to the employment of released bonded labor on the work entrusted to
him.
Employment of scarcity labour
If Government declares a state of scarcity or famine to exist in any

village situated within 16 kilometers (10 miles) of the work, the
Contractor shall employ upon such parts of the work as are suitable for
unskilled labor, any person certified to be in need of relief by the
Employer, or by any person to whom the Employer may have delegated
this duty in writing, and shall be bound to pay to such persons wages
not below minimum which the MAHINDRA WORLD CITY
Page 38 of 60
(JAIPUR) LTD., may have fixed in this regard. Any dispute which
may arise in connection with the implementation of this clause shall be
decided by the Site-In-Charge or other competent authority, whose
decision shall be final and binding on the Contractor.
The Contractor shall employ any famine victim, convict or other labor
of a particular kind or class, if ordered in writing to do so by the
Employer or other competent authority.
Minimum age of laborer
The Contractor shall not employ:
* any person who is under the age of 15 years

* who does not produce a valid certificate of vaccination against
small-pox in respect of himself/herself as well as all the members
of his/her family.
Dismissal of workmen
The Contractor shall, on the request of the Landscape Architect/Site-In-

Charge, immediately dismiss from the works any person employed
thereon by him who may, in the opinion of the Landscape
Architect/Site-In-Charge, be incompetent or misconduct himself, and
such person shall not be again employed on the works without the
permission of the Landscape Architect/Site-In-Charge.
Labor camp
No labour camp will be allowed to be set up inside the site.

79. other persons engaged The Employer, with concurrence of the Landscape Architect/Architect,
by employer reserves the right to use the premises and any portions of the site for the
execution of any work not included in this Contract which he may
desire to have carried out by other persons, and the Contractor is to
allow all reasonable facilities for the execution of such work but is not
required to provide any plant or materials for the execution of such
work, except by special arrangement with the Employer. Such work
shall be carried out in such manner as not to impede the progress of the
works included in the Contract, and the Contractor is to be responsible
for any damage or delay which may happen to or be occasioned by such
work.
The Contractor shall provide reasonable facilities for the use of his
scaffolding, tools and plant etc., by the Landscape Contractors of other
works for their work, without any extra cost, by special arrangement
with the Employer.
80. Contractor responsible The Contractor will be responsible for the coordination of all the work,
for coordination including that of his Landscape, and cooperating with all other agencies
for arranging runs of all services and working to the requirements and
layouts of the specialist trades, in all matters necessary for the complete
timely execution of the work as desired.
81. Water and electricity The Contractor will have to make his own arrangements to supply water
and electricity to the various works.
82. Miscellaneous Clearing of debris
All shavings, cuttings and rubbish as it accumulates from time to time

during the progress of the work and on completion, including that of
Landscape Contractors and special tradesmen, are to be cleared and
carted away by the Contractor, and all materials condemned by the Site-
Page 39 of 60
In-Charge/Landscape Architects are to be removed from time to time

by the Contractor, without any extra charge.
Objects of antiquity
All objects of value or antiquity found on the site shall remain the
property of the Employer, and such findings shall be immediately
reported to the Landscape Architect/Employer.
Work borrow pits
The Contractor shall not be entitled to claim compensation if there is

any delay in the execution of the work on account of water standing in
burrow pits and compartments. The rates are inclusive for hard or
cracked soil, excavation in mud, sub-soil water or water standing in
burrow pits, and no claim for extra rate in this regard shall be
entertained, unless otherwise expressly specified.
Advertisements
The Contractor shall not affix in place any placards or advertisement of

any description, or permit the same to be affixed or placed in or upon
any hoarding, gantry, building, or structure on the works or premises,
other than that approved by the Employer/Landscape Architects
83. Conditions of contract It must be clearly understood that all the Conditions of Contract are
to be strictly enforced intended to be strictly enforced and that no extra charges in respect of
extra work will be allowed, unless they are clearly outside the spirit and
meaning of the conditions or unless such work shall have been ordered
in writing by the Site-In-Charge/Landscape Architects.
Materials suitable for filling or other use shall be stacked in convenient

places. Materials not useful in any way shall be disposed of. The Site-
In-Charge shall be the final authority as to what is useful rubble. The
site shall be left clean of all debris at the completion of the work.
Page 40 of 60
SECTION: 5
SPECIAL CONDITIONS OF CONTRACT
Page 41 of 60
1. GENERAL -TERMS OF REFERENCE FOR WORK EXECUTION
Terms of Reference Description

Contractor has to work as per the designs and lineout details
provided by Landscape Consultant. Difficulty on site in execution
a) Design & Details
as per the plan/ design has to be brought to the notice of site-in-
charge immediately.
Any discrepancies in the design subject to execution hurdles and
alteration required should be reported to site-in-charge and the same
should be improvised by the landscape consultant or as per
instruction of the site-in-charge and contractor shall have to work
only after due approval of the modification.
The landscape site should be free of any Construction Debris or
wild vegetation. It shall be responsibility of the contractor to ensure
that the site is in working condition as per instruction of the site-in-
charge. The contractor shall also ensure proper grading of the
Landscape Site
b) landscape site in terms of aesthetics as well as drainage providing
Preparation
mounts and slopes with a gentle slope towards natural drainage
direction All rubbles and debris if any and dispose it of in the
suitable location possibly in low lying areas as identified by the
contractor and approved by site-in-charge.
The Soil to be used as Top Soil(Good Soil/earth) for all plantation
works shall be primarily imported fertile soil from agriculture fields
off the site.
The contractor should get the soil test report and accordingly with
experts and consultants would meet the requirement for additives
c) Soil Testing and soil conditioner to possibly maintain pH value of the soil
between 7.0 - 7.5 before plantation works. Also after every 6
months or as required on poor performance of the plantation shall
accordingly get the soil tested and measures taken for maintaining
the pH value within acceptable range. Also Contractor shall
undertake treatment as per advice of the experts to soil
conditioning during the entire maintenance period
Contractor should employ qualified & experienced garden
supervisors and adequate number of gardeners to maintain the
quality of garden and tree plantation to the satisfaction of
d) Manpower Employment Horticulture Department. A senior supervisor [M. Sc. (Horticulture)
or B.Sc(Agriculture) with 8-10 Years of relevant & similar work
Experiences. should be deputed as an overall in-charge of the whole
contract who will ultimately report to the Site-In-Charge
The deployment of the maintenance staff should be adequately
provided as per the Schedule of the Maintenance Staff
The complete work can be chosen for completion in stages provided

the same is submitted as a structured schedule for work completion
showing stage completion as milestone before start of the work and
hence approved by the site-in-charge. The stage completion of the
e) Handing Over work shall be deemed as part completion and liable for maintenance
period of the contract agreement. However, final completion liable
for issue of the virtual completion of the work shall be only after
completion of the total work for which the contract agreement has
been made of Date of
Running Bill shall be raised based on virtual completion of the
partial scope of work as milestone completion of the work order
f) Billing
value. Billing will be done on the basis of actual quantum of work
done.
Tree /Palms Plantation would be considered as per number of trees
Page 42 of 60
Shrubs/Ground Covers/lawn plantation would be considered as per

area in Sq.mt with spacing of shrubs as per specification provided in
the drawing/BoQ
For evaluation of maintenance work, a joint inspection will be
carried out on 25th day of every month or the 1st working day after
the schedule date.
a) Damage to lawn/ hedges/ edges/ ground covers etc.: Term
Damage represents any kind of unhealthiness or un-acceptable
look to the garden features. A fine of Rs.500/-per sq.mt shall be
imposed on unhealthiness/mortality of the shrubs on basis of the
plantation bed. The contractor shall be required to attend special
care to the plantation bed. In absence of proper care and attention,
the plantation bed not in state of acceptance by Site-In-Charge,
further fine of Rs.50/- per/ Sq/mt/week shall be levied till the
period the state is re-instated into good health by application of
fertilizers/insecticides/pesticides . In case of the plants suffering
mortality, the same shall be replaced immediately to avoid penalty.
g) Penalty
b) Dieing of Designated trees: the term Designated Tree represents
the new plantation or the trees computed for their maintenance
during joint inspection after award of contract. Death or Poor
maintenance state of trees will cause fine @ Rs. 500/- per tree at
the end of the month. The trees have to be supplied and planted at
the respective location at the earliest, failing which will lead to
increase in penalty by 10% i.e. Rs. 55/- per Tree upto the time the
tree is replaced. The fine shall be deducted from the quarterly stage
payment.
The lawns shall be maintained green with the desired maintenance

effort. The contractor shall be liable for being fined in event of the
lawns not performing as desired by the owner. The fine shall be
Rs.50/- per sq.mt of the lawn area not found acceptable or dead.
The arrangement of transport for disposal of waste, shifting of
Disposal of Waste- plants, etc. has to be made by the contractor. The generated waste
h) General Cleanliness of has to be disposed off within 48 hrs of generation or as instructed.
Landscape Site Failing which arrangement shall be made for disposal of the same
by the owner at risk and cost of the landscape contractor.
It is the contractors responsibility to keep the garden in green,
healthy and in proper condition all the time. owner will provide the
place for disposal of garden waste within premises for Vermi-
composting to be compulsorily adopted by the Contractor
i) Provision for Water For Trees-@ 20 ltrs/every alternate day of watering should be
provided to each of the tree planted.
For Shrubs-@15 ltrs/sq.mt/every alternate day of watering should
be provided by the contractor
For Lawns-@ 25 ltrs/sq.mt/weekly requirement of watering should
be provided by the contractor
Water will be provided by owner free of cost. Wherever irrigation
tap connection is not available, watering should be done with water
tankers or appropriate methodology. The maintenance of tankers or
any appropriate system shall be integral responsibility of the
Contractor to meet the watering requirements of the Trees, shrubs
and lawns under any circumstances.
Owner shall provide point electrical connection wherever possible
but in case of un-availability of the same it will be Contractor's
responsibility to make arrangement for Diesel Genset to meet their
j) Electricity
requirement. The use of electricity shall be on chargeable basis. The
contractor shall install electricity meter and shall pay for the
metered readings as per the rates settled with the owner.
Page 43 of 60
The Contractor shall adhere to the maintenance schedule During the

maintenance period of all the Plants, contractor shall be responsible
for any replacement towards mortality and the trees or the area of
the plantation under shrubs/creepers/ground covers etc should be in
k) Maintenance
healthy condition during the inspection conducted by the site-in-
charge on every 25th day of the month to avoid the penalty
clause(g) and also subsequently amounting to holding of the
payment due for quarterly installment..
Contractor shall maintain record of maintenance & operations on
site and submit daily report for all the areas certified for virtual
completion of the work. Also the contractor shall take note of the
observation of the site-in-Charge or his representative/Horticulturist
and seek compliance of the same at the earliest before nearest
schedule to avoid any penalty as per penalty terms
The Contractor shall submit daily report on the deployment details
as well as work planned for the day to the Site-In-Charge in
prescribed format. All instructions and activities shall be recorded
as per the desired format. Any problem or hindrance shall be
l) Reports brought to notice in the daily report along with evidence in form of
photographs. Also the contractor shall be required to maintain Stock
Register at all times for the planting material sourced to Owners
site and Supply for plantation in the Nursery maintained by the
Contractor.
The Contractor shall be required to set-up Office for its staff and
Nursery with good micro-climate to store the supply of the plants.
Nursery Maintenance
m) In case of propagation of the plants in the nursery, the same shall be
Office Set-up
used on site only.
Contractor shall mandatorily have Vermi-Composting System

developed at appropriate location where all the pruning wastes,
organic wastes shall be dumped with weeds, weed seeds or bulbs,
stones etc., mix it well in the soil in the ratio ( 6:1), level as per
n) Vermi-Composts
grade.( point of unloading 0-50m). The process shall be require
approval of the site-In-Charge and periodic maintenance of the
activity. Approval of site in charge prior to dispatch of material for
use on site is must.
The Payment shall be processed on the basis of the area handed over
after development and planting as completion of the milestone .The
certificate and the date there in for the virtual completion of the
work shall entitle the contractor for continuance of the maintenance
for 12 months.
Payment Terms based on the item rates for the quantum of the
certified virtual completion of the work shall be as follows
30% -On Virtual Completion of the Milestone

o) Payment Schedule 15%-After 3 Months of the virtual Completion
15%-After 6 Months of the Virtual Completion
The site-In-Charge shall be fully empowered to hold the payment in

case the contractor is observed negligent to the maintenance works,
mortality of plants not attended by the contractor for immediate
replacement of the same by healthy plants.
2. PLANTING SCHEDULE
I. Tree Plantations
Page 44 of 60
Sl.No Terms of Reference Instruction & Procedures

A. Supply of Trees
All plant materials shall be healthy, sound, vigorous with good
foliage, Plants supplied shall be conforming to the names listed on
1 Physical Condition the plant list. No plant materials will be accepted if branches are
damaged or broken. All material must be protected from the sun and
weather until planted
All plant materials shall be free from plant diseases, insect pests, or
their eggs, and shall have healthy well-developed root systems.Plant
2 Health of Trees material shall be well formed and shaped true to type and free from
disease, insect and defect such as knots, windburn, sun-cold, injuries,
abrasion or disfigurement.
In no case, the specification of the material in terms of height, Girth
& Foliage as mentioned in the BoQ shall be acceptable for plantation
works.
In case of in-availability of the particular species or the planting

material as per specification in BoQ ,the alternate species or lower
specification as the case may be shall have to be approved by site-in-
3 Specification of Trees
charge in special case after due confirmation of the landscape
consultant.
3. Lower Specification as mentioned in the BoQ accepted by the

site-in-charge under special condition shall be re-negotiated for
a lower rate depending upon the specification of the plants
sourced by the contractor.
B. Planting of Trees
Minimum Pit Size for all trees should be of the size 1mtX1mtX1.2mt
1 Pit Size
Incase of larger trees pit size should be of 1.2mtX1.2mtX1.5mt
The soil shall be essentially good Earth mixed with 1/3rd of
Soil Preparation- decomposed farmyard manure along with additives like Gypsum,
2
Preparation of tree pits: sulphur ,Zinc Sulphide (ZnS)etc to maintain ph-value of the soil
between 7 - 7.5.
Planting of trees and stacking / propping to protect the trees from
wind and irrigate on need basis. Maintain the tree basins - free of
weeds by regular hoeing.
Planting the tree with root ball in the pit (tin grown / poly bag grown)
3 Planting of trees after removing carefully and without disturbing the root. Pressing the
soil firmly around the tree planted. Preparing the basin around the
tree and watering after staking and tying. The plant should be well
maintained, disease free, well trimmed at the time of handing over.
In case of death of the plant the contractor need to replace the same
with equally well grown healthy plant.
To ensure protection from Winds-staking/ propping it with bamboo

tripod using jute string. In all condition, tree should be standing in
4 Stacking / Propping erect position
The staking should have anti-termite treatment .

All the planting materials shall be periodically examined for termite
attacks or plant disease and appropriate measure (application of
Fertilizers /organic solid liquid manures/ growth regulators/ pesticides as per need, weeding
manures and liquid regularly so as to keep the plant healthy all the time) shall be
5 manures, spray bio- undertaken for entire period of the contract..
insecticides, parasites,
predators
Required at the time of Plantation and entire period of maintenance
as per Maintenance Schedule
Page 45 of 60
Making basin around Trees ( 1mtr dia clear space) and maintaining
Tools and Tackles/Hose-pipes, tractor mounted Water Tankers or as
6 Watering Arrangement required in sense all arrangement for water distribution and watering
equipments/manpower to be managed by the Contractor for watering
the trees;
C. Handing Over of Trees
All Tees planting should have Name Tag with name of the relevant
species and well placed on trees with good visual characteristics.In
1 Name Plate for Trees
case of row plantation of similar species,the same can be repeated at
definite intervals may be on every 5th tree from the start
D. Maintenance of Trees
Apart from the essential watering of the plants as per the maintenane
manual ,Nurture the trees with organic solid manures and liquid
manures, spray bioinsecticides, parasites, predators to protect the
trees from pest and disease. Amend the soil on regular basis with
proper soil amendments to keep the pH level between 7 - 7.5 after
completion of (12)Twelve month maintenance period the plants
should be maintained by regular watering, weeding, replacing dead
plants, applying pesticides, Use of plant physical protection
1 Maintenance of Trees
measures etc. so as to grow them vigorously.
Newly Planted should be maintained by 1) Watering every alternate
days @ 20 ltrs/watering cycle 2) Applying FYM @
10kg/ tree/ annum 4) Trimming, prunning as & when required under
guidance of the site-in-charge etc.
3)The Trees should have proper staking so as the tree should stand
erect till the Tree settles with no possibility of bending due to Wind
or Rain
I. Shrubs Plantations
Sl.No Terms of Reference Description
A. Supply of Shrubs,Creepers,Ground Covers
Plant material shall be well formed and shaped true to type and free
Health of Shrubs/Ground from disease, insect and defect such as knots, windburn, sun-cold,
Cover/Creepers etc injuries, abrasion or disfigurement.
All plant materials shall be healthy, sound, vigorous with good
foliage, and free from plant diseases, insect pests, or their eggs, and
shall have healthy well-developed root systems. Plants supplied shall
be conforming to the names listed on the plant list. No plant
materials will be accepted if branches are damaged or broken. All
Physical Condition material must be protected from the sun and weather until planted.
The species should be in appropriate specification in terms of height
& Foliage as provided in BoQ.
Species below specification shall be liable for deduction of the item

Specification of Shrubs rate as agreed upon.
B. Planting of Shrubs,Creepers,Ground Covers
As per the specification and depth should be minimum 300 mm deep
exclusive of the top 50mm where top edge is defined for watering
and flooding. The plantation bed shall be the basis of all billing
Bed Sizes purpose including maintenance charges to be paid to the contractor
Dig and remove all weeds, debris, rubbles, and stones from 18"
depth of the surface soil level to be maintained in due course. The
soil shall be essentially good Earth mixed with 1/3rd of decomposed
farmyard manure along with additives like Gypsum, sulphur etc to
Soil Preparation maintain ph-value of the soil between 7 - 7.5.
Page 46 of 60
Preparation of soil for grass, ground cover, edges, shrubs and flower
beds: . Then prepare the same soil with 2-3" thick layer of well
decomposed, weed free farm yard manure or vermicompost. Treat
the soil with chloriphyriphos / Lindane / Neemcake depends upon
the infestation of soil borne pests. Treat the soil with proper
herbicide to control the weeds only on need basis. Finally level the
soil as per the drawing or planting details.
Preparation of pits for shrubs, creepers and hedges : The bed shall be
prepared with good earth mixed with 1/3rd quantity of decomposed
faryard manure along with
a sapling of shrubs, ground covers, lilies, suckering plants etc. as per

design plant spacing 30-60 cm. maintaining( application of liquid
manures/ growth regulators/ pesticides as per need, weeding
regularly so as to keep the plant healthy all the time) it for a period
of 12 Months days from the date of virtual completion of
Planting development work
Planting shrub/ground cover- Planting of shrub in the bed prepared
earlier by filling garden soil and manure (67:33 ratio).Planting the
shrub with root ball in the pit (tin grown / poly bag grown) after
removing carefully and without disturbing the root. Pressing the soil
firmly around the tree / shrub planted. Preparing the bed around the
shrub and watering after staking and tying. Maintenance of
shrub/ground cover up to 12(Twelve)months by regular watering and
attending the inter-cultivation practices such as weeding, racking,
watering gap filling ,free of weeds by regular hoeing. etc. The plant
should be well maintained, disease free, well trimmed at the time of
handing over. In case of death of the plant the contractor need to
replace the same with equally well grown healthy plant. Nurture the
shrubs/ground cover with organic solid manures and liquid manures,
spray bio-insecticides, parasites, predators to protect the trees from
pest and disease. Amend the soil on regular basis with proper soil
amendments to keep the pH level between 7 - 7.5
Planting hedges / edges - Planting of hedge / edge in the ground
prepared earlier by filling garden soil and manure Preparing a pit of
require size (for accommodating the root ball of plant) Planting the
plants in 2/3 rows (as per instructions) at specified distance with
root ball removed carefully and without disturbing the root ball from
poly bag. Pressing the soil firmly around the plant Preparing the
basin for watering. Maintain hedge / edge up to two months by
regular watering and attending the inter-cultivation practices such as
weeding, raking, gap filling, trimming and pruning etc. The hedge /
edge should be well maintained, disease free, well trimmed at the
time of handing over. In case of death of the plant the contractor
need to replace the same with equally well grown healthy plant.
Planting Ground cover - Planting of ground cover plants in the
ground prepared earlier by filling garden soil and manure. Preparing
a pit of require size in the ground. Planting the ground cover plant
root ball at nine inches apart in the pit after removing carefully and
without disturbing the root ball. Pressing the soil firmly around the
plant Preparing the basin around the plant watering. Maintenance of
ground cover up to two month by regular watering and attending the
inter-cultivation practices such as weeding, raking, gap filling,
trimming and pruning etc. The ground cover should be well
maintained, disease free, well trimmed at the time of handing over.
In case of death of the plant the contractor need to replace the same
with equally well grown healthy plant.
Fertilizers /organic solid
manures and liquid
manures, spray
bioinsecticides, parasites, Required at the time of Plantation and entire period of maintenance
predators as per Maintenance Schedule
Page 47 of 60

Watering Requirements required to be managed by the Contractor for watering the trees;
C. Handing Over of Shrubs
The Shrubs planting should be done in the selected stretch as
Date of Handing Over released complete /partial scope of work
The Shrubs planting shall be provided with Name Plate to specify the
type of shrubs planted as per the bed and in case of longer beds at
appropriate intervals so that the same can be identified at distant
Name Plate for Shrubs observations
D Maintenance of Shrubs
After completion of 12(Twelve) month maintenance period the
plants should be maintained by regular watering, weeding, replacing
dead plants, applying pesticides etc. so as to grow them vigorously.
b) Trees & plants: should show regular healthy growth through
regular maintenance by manuring, fertilizing. Use of plant protection
measures, adequate watering etc.
1. Maintenance of all developed features ground cover, hedges and
shrubs etc. of the complex. Maintenance work includes timely
pruning, weeding and cutting of ground cover plants, hedges, edges,
plants planted in the areas mentioned above. Application of
fertilizers, manure, etc to the lawn, plant and spraying pesticide etc.
as and when required.
2. Seasonal flower beds have to be replaced as and when required
(approximately thrice in a year). Plant species can be changed w.r.t.
season only in consultation with horticulture department.
3. Removal of wild grass normally found growing in rainy season
by cutting and/or uprooting so as to keep the areas free of grass.
A. Supply of Lawns
Plant material shall be well formed and shaped true to type and free
from disease, insect and defect such as knots, windburn, sun-cold,
injuries, abrasion or disfigurement.
Supply and planting of lawn: Planting of lawn grass ( Paspalum/
cynadon sp./ zoasia sp./ stenotaphrum etc) as per drawing without
disturbing the desired gradient and level, maintaining (forking,
mowing, weeding, fertizer application) it for a period of 12 Months
of completion of virtual completion( No irrigation system provided,
however water is available free of cost). Contractor has to make his
own arrangement for water distribution)
Supply and Laying of carpet lawn (zoasia sp.) as per drawing
without disturbing the desired gradient and level, maintaining
(forking, mowing, weeding, fertilizer application) it for a period of
12 Months of virtual completion of development work( No irrigation
system provided, however water is available free of cost). Contractor
Specification of Lawns has to make his own arrangement for water distribution)
B. Planting of Lawns
Top 200 mm depth: The soil shall be essentially good Earth mixed
Soil Preparation with 1/3rd of decomposed farmyard manure along with additives like
Gypsum, sulphur etc to maintain ph-value of the soil between 7 - 7.5.
Page 48 of 60
Planting Dibbling of grass: Fine level the soil, apply thin layer of sand,
vermicompost and Neemcake mixture of 1" thickness and dibble the
grass at 3" distance. Roll the lawn after planting. Irrigate the lawn
regularly. Remove weeds on periodical basis. Nurture the lawn with
organic, bio-insecticides, parasites, predators to protect the lawn
from pest and disease. Mow the lawn regularly and maintain the
grass at 50 mm (2") height. Trim all the edges after mowing, keep
the edges with trees, shrubbery and flower beds clean.
The Carpet Grass primarily Japonica would be brought in Rolled

carpet form in healthy condition and shall be placed on the alreday
prepared surface and Light roller should be used for setting of the
adges for a smooth carpet lawns. The watering of the lawn should be
sufficient for thriving of the lawn to grow then vigorously
Fertilizers /organic solid Required at the time of Plantation or as per maintenance schedule
manures and liquid
manures, spray bio-
insecticides, parasites,
predators
Watering Requirements required to be managed by the Contractor for watering the trees;
C. Handing Over of Lawns

The lawn areas should be considered fit for handing over once the
lawns have settled and the surface starts showing the lawn effect.
D. Maintenance of Lawns
For 12 (Twelve) month maintenance period the Lawns should be
maintained by regular watering, weeding, replacing dead Spots,
applying pesticides etc. so as to grow them vigorously.
The Lawn should be regularly mowed and maintained as good green
carper till the final completion of the maintenance period as per the
maintenance schedule.
3. MAINTENANCE SCHEDULE
3.1 GENERAL OBLIGATIONS
a. The Landscape Contractor shall maintain the works for the maintenance period. The Employer reserves
the right to terminate the maintenance period at any time, whereby no additional charges are to be made
by the Landscape Contractor to the Employer.
b. The extend of the landscape to be maintained by the Landscape Contractor shall be deemed to cover and
include all softscape landscape areas within the overall project boundaries as shown on the drawings
including any existing soft landscape not affected by the Sub-Contract works and retained intact or nearly
so through the end of the Sub-Contract period as well as all the landscape works covered in the Sub-
Contract scope of works. No additional charges will be allowed unless specifically agreed to by the
Landscape Architect in writing.
c. The Landscape Contractors Horticulturist shall inspect the site every day and shall submit report to the
owner on their actions and closure of the pending works .Also on weekly basis, the Contractors
Horticulturist shall prepare a brief schedule of operations planned for the week with target dates.
d. The daily report and the weekly schedule shall be running record of proposed operations which would be
checked at the maintenance inspections every month. If in the opinion of the Landscape Architect/Site-In-
Charge, the maintenance works have not been satisfactorily carried out according to site conditions and
the specifications, the quarterly payment will be withheld until the works have been satisfactorily carried
out besides the penalty as in the penalty clause.
e. The Landscape Contractor shall take all necessary measures to ensure that all pot plants, trees and shrubs
and other plants shall thrive and become established within this period. All landscape areas will be
Page 49 of 60
inspected and list of remedial works issued after each inspection. All items on the remedial lists are to be
carried out by the time of the next inspection.
f. The Landscape Contractor shall keep the landscape areas clean and tidy at all times and dispose of all
waste materials arising from the cleaning.
g. If the Landscape Contractors works are found to be unsatisfactory, payment shall be withheld and the
maintenance period extended for the period of time that the landscapes maintenance has not been
satisfactory. All cost associated with the extension of time shall be borne by the contractor.
3.2 MAINTENANCE OF PLANTED AREAS : TREES, SHRUBS, CLIMBERS, HERBACEOUS PLANTS

AND GROUNDCOVERS
a. The Landscape Contractor shall water all trees, palms, shrubs, groundcover, herbaceous plants and other
planting areas as often as necessary to keep the ground moist all around and to the full depth of the roots.
b. Only fresh water shall be used for the Works. The Owner shall provide water requirement of the planting
materials but watering shall be all time (Work presence of the Contractor on site) responsibility of the
Contractor till the time proper system (Irrigation) is placed by the Owner. Landscape Contractor shall supply
all water requirements at his own costs. The Landscape Contractor shall supply his own hoses and sprinklers
to distribute the water.
c. Water shall be applied using an approved rose or sprinkler so as not to cause compaction or wash-outs of the
soil or loosening of plants. The Landscape Contractor shall immediately make good any such damage.
d. All planting beds are to be kept in a weed free condition with a weeding operation as per maintenance
schedule or more regularly as required. All weeds, stones and rubbish collected from this operation shall be
removed from the site by the Landscape Contractor.
e. Firming up and adjusting of stakes/ties shall be carried out monthly to ensure that the trees and shrubs are
firmly held in ground. If required, guy ropes or tree ties shall be adjusted, tightened or loosened. If tree ties or
ropes are rubbing the bark of the trees, the ties are to be taken off and retied. Any damaged branches are to be
carefully pruned and the wounds sealed.
f. All protective fencing is to be maintained and kept in good condition as long as required on site.
g. All shrubs and groundcovers are to be reviewed monthly and pruned as per maintenance schedule or as and
when required during the Maintenance Period to promote bushy growth and good flowering characteristics.
The shrubs shall be checked and all dead wood, broken, damaged or crossed branches shall be cut back,
depending on species.
h. Pruning for all plants shall be carried out as follows :
Pruning is to be done with the cut just above and sloping away from an outward facing healthy bud.
Removal of branches is to be done by cutting flush with the adjoining stem and in such a way that no
part of the stem is damaged or torn.
Ragged edges of bark are to be trimmed with a sharp knife.
Any cuts or wounds over 25mm diameter are to be painted with an approved sealant such as Arbrex
after trimming.
All pruning are to be cleared up and removed from operation site after pruning for Vermi-
Composting.
i. All hedges, mat forming herbaceous plants and groundcover plants shall be clipped with shears as often as
necessary (at least monthly) to maintain a tidy appearance. Tall hedges are to be cut to forms shown on the
drawings.
j. Selective pruning of flowering plants shall be done where special flowering characteristics are required such
as for Ixoras, Hibiscus, Bougainvillea etc
k. The Landscape Contractor shall on continual basis supervise and attend to fertilizer needs/disease
control/termite or fungus control as maintenance operations during the entire period of contract An approved
fertilizer/insecticides/pesticides shall be applied to each plant at the rate provided in the maintenance schedule
or as suggested by the Horticulture Advisor to the Owner. Fertilizer shall apply the fertilizer evenly spread
over the entire area and lightly forked into the soils. All areas shall be well watered immediately after
application of fertilizer.
Page 50 of 60
l. The horticultural requirements of different plants or areas may involve variations to those techniques (such as
the use of organic liquid fertilizers for sensitive plants) and variations in method will be authorized as
required.
m. Mulching. An additional 25m deep mulching layer is to be spread over all planted areas (except groundcover
and turf), once every 6 months or as specified in Maintenance Schedule.
n. The Landscape Contractor shall make regular weekly checks to ensure that the plant material is insect and pest
and free
3.3 MAINTENANCE OF LAWN AREAS
a) The Landscape Contractor shall mow all lawn areas using approved cutting equipment to maintain a close
sward to a height of not less than 20mm and not move than 45mm for all grass types. Mowing shall be carried
out weekly, except in dry weather and grass shall not be allowed to flower between cuts. All clippings to be
gathered up and removed.
b) All grass areas are to be watered during dry weather as often as is required to keep the grass green and the soil
moist. The Landscape Contractor shall make weekly inspections are to be made to determine the need for
water.
c) Fertilizer of NPK value 10-15-15 or similar approved be spread at a rate of 40gm/m2 over all grass areas at 6
months intervals using approved spreading equipment to give an overall even spread. Every three months
between the NPK application the grass areas will receive and application of 46-0-0 at 1kg/100m2.Grass areas
that have been fertilizer shall be watered immediately. If the tops of the Anoxopus turn red a light application
of lime using magnesium, limestone or agricultural lime in powder form is to be applied in dry weather at a
rate of 50g/m2. After application this is to be well watered into the soil.
d) The Landscape Contractor shall apply top dressing of not more than 15mm depth of fine sand and granulated
compost raked and spread evenly over the lawn areas to fill in the low spots and level the grass areas. The next
top dressing shall be applied only after the grass has grown to a mow able height.
e) There shall be at least two applications of top dressing during the maintenance period. If depressions or bumps
over 25mm deep or high occur in turf areas during he maintenance period these are to be leveled out by lifting
the turf and raising the soil level with sand/compost mix or trimming soil to level grades, followed by re-
turfing.
f) Grass areas are to be kept free from weeds, annual grasses, fungus and insect attack, and stones or other debris
throughout the maintenance period as often as is required. Assessment of these operations is to be prepared on
the basis of the bi-weekly maintenance inspection chart.
g) If compaction or consolidation takes place or hard panning or baking of the soil occurs, the soil areas are to be
well watered first and lightly loosened by mechanical means such as spiking, slitting or hollow tinning using
equipment approved by the Landscape Architect.
3.4 DETAILS OF PERIODIC MAINTENANCE ACTIVITIES
Frequency
Sl.No Operation (Times) Period/Duration after Handing Over
1 Irrigation As per Demand or as specified under
(a) In Summer 15 Month-Every Alternate Day
(b) In rainy Season 5 to 7 Monthly or as per climatic condition
( c) In winter 10 Monthly
Page 51 of 60
2 Weeding- 2 Monthly
3 Forking of the Plants & Shrubs- 2 Monthly
4 Edging- Once Monthly

5 Grass Cutting- 2 Monthly
Monthly or as per instruction of the
6 Trimming of Shrubs/Ground Covers: Once site-in-charge
7 Pruning of Big Trees 2 Yearly

Mulching i.e., 50mm thick layer fine
powdered FYM or Cocopit /vermin-
8 compost Once Once in a month
9 Fertilizing
Lawn (NPK value 10-15-15)-250

Grm/sq.mt at interval of after planting Quarterly/Half Yearly as instructed
(a) with enough watering Once by Site-In-Charge
Shrubs & Ground Covers etc @ 50 Quarterly/Half Yearly as instructed
(b) grm per sq.mt with enough watering Once by Site-In-Charge
Quarterly/Half Yearly as instructed
( c) Trees @ 50 grams per Tree Once by Site-In-Charge
Gypsum+ Sulphur for maintaining pH

Value at 7 to 7.5 @ 200 grm/sq.mt or as
instructed by Site-In-Charge in
consultant with Horticulturist or
10 Landscape Consultant Once Yearly
Site Cleaning & maintenance of General As & When required but site should
11 Appeal of the Site Daily be maintained clean
3.5 DETAILS OF MAINTENANCE STAFF REQUIREMENT
As per the minimum need of the maintenance requirement to the landscape developed area on gross basis as
per the maintenance schedule, the following number of the person shall be required for desired activities based
on the 5 Acres(20235 sq.mt) area under landscape.
Sl.No Manpower Description Nos

1 Trained Gardeners+ laborers 12
2 Supervisor 01
3 Tractor Driver & Helper 02
4. Total Manpower (per 5 Acres) 15 Nos
Besides, the contractor shall have to deploy a horticulturist as per criteria specified in the Section-5 :
Special Conditions of Contract Clause1(d)
4. SOIL TESTING
The Contractor shall be required to get the soil test done as per instruction and supervision of the Site-In-
Charge for ensuring the soil correction before the plantation works. The soil test shall be done @ minimum 20
Nos, the location selected randomly by the Site In-Charge.
Page 52 of 60
Sl.No Parameters Acceptance value

1)
pH Value 7.5
2)
Nitrogen Between 25-60 ppm
3)
Total Soluble Solids 0.01%
4)
Chloride 20 mg/kg
5)
Carbonates Between 1 & 60%
6)
Organic Matter Between 1 & 60%
7)
Phosphorous Between 4 & 5 ppm
8)
Calcium Between 150 & 250 ppm
9) Between 11 & 20%
Magnesium
Between 7 and 10 ppm
10)
Salinity Between 420 & 12 Months0 ppm
11)
Sodium Less than 5%
12)
Potassium Between 90 & 125 ppm
13)
Sodium Adsorption Ratio ( SAR) Between 12% to 15 %
14)
Sulphure as Sulphate Between 7 & 12 ppm
15)
Iron Between 5 & 20 ppm
16)
Boron Between 0.5 & 1.0ppm
17)
Zinc Between 1.2 & 3.5 ppm
18)
Copper Between 0.3 & 1.0ppm
5. PLANTING PRACTICES-APPLICATION
A. REQUIREMENT OF SOIL PREPARATION, PLANTING AND MAINTENANCE

MATERIALS
a. Soil Conditioner
Soil Conditioner shall be Peat Moss, organic compost composted rice hulls or other approved fibrous
organic matter suitable for mixing with topsoil to make a friable growing medium for plants. It shall be
resistant to rapid decay, free from soluble salts (below 900ppm), pH 6-7, free from large lumps or debris.
Coco-Peat will not be accepted.
A sample shall be submitted to and approved by the Landscape Architect prior to installation.
Page 53 of 60
b. Organic Compost
Organic compost shall be an organic vegetable compost produced thorough a horticultural or industrial
composting process. Compost is to be clean, decomposed, smell free, and free of any debris, refuse, clay or
visible fungus. A sample and test data is to be submitted for approval before use. All compost is to be
sterilized before being packed for transport. Any odorous materials delivered to site will be rejected. Any
vermin resulting from use of organic compost will have to be controlled by the Landscape Contractor
within 12 hours.
c. Peat Moss
Peat Moss shall be fibrous fresh water peat from vegetable fibre. Peat will have a pH of 5.8 6.5 and shall
be free of soluble salts greater than 900 micromos; Peat shall be free of lumps, sticks or stones greater
than 5mm.
d. Composted Rice Hulls

Rice hulls shall be partially composted and free from live rice or weed seeds. The rice hull compost shall
be nitrogen stabilized and free of particles greater than 5mm.
e. Sand
Sand shall be clean, coarse, well graded material, free from soluble salts. Particles shall range in size so
that 80-100% passes the 1mm sieve and 0-50% passes the 250 micron sieve.
f. Fertilizers
Chemical fertilizers shall be approved granular fertilizers. Fertilizer may be single element or compound,
normal or slow release compound fertilizers. They shall be stored in waterproof sealed bags under shelter
away from water and direct sunlight. Samples shall be submitted to, and approved by the Landscape
Architect, before use in the Works.
Organic fertilizers shall be organic products such as organic liquid fertilizer, pellets or granules
manufactured primarily from organic materials. These products are to be from accredited sources and
technical data indicating sources of origin and manufacturing process must be submitted and approved
before use. Animal by-products must be sterilized before being packed for transport and odorous
materials used on site will be rejected.
g. Mulches
Mulches shall be an approved friable-composted organic material such as Oil Palm husks, organic
compost or an approved mix. Coco-peat will not be allowed unless mixed in a proportion of 50-50 with
another mulching material free from soluble salts or toxic materials and resistant to rapid decay. Mulches
shall have a pH of 5.5 - 7.0. Samples are to submitted to the Landscape Architect and approved before
use.
Mulches are to be applied in a 50mm thick layer over the entire surface of shrub and groundcover areas.
Mulching is to be re-applied to expose soil in planting areas every 3 months after initial installation until
the end of the maintenance period or until complete surface cover by vegetation is achieved.
Initial mulching is to take place within two days of installation of planting.
B. STAKING & SUPPORTS
a. General
Page 54 of 60
i. Stakes shall always be used when planting instant trees, standards and single stem palms and for tall
shrubs as indicated in the drawings.
ii. Stakes shall be mangrove poles, bamboo or equal and shall be appropriate to the size of the plant to be
supported.
b. Guying
i. Guying shall be used for large trees or palms. A minimum of three wire guys are to be used per tree.
Each guy wire is to be fastened by a loop around the lowest branches of the tree at the junction with the
main trunk or stem. Loops are to have protective rubber or plastic hose to prevent chafing and are to be
fastened back to the guy wire by means of U-clamps. Wire shall be 2.5mm PVC coated GI wire, green
colour. Palms shall have 5mm x 3mm x 30mm battons fastened about the trunk with GI wire at the
height where the guy wires are to be secured. Guy wires will fasten to the battons and not to the main
trunk.
ii. Guy wires are to be fastened at ground level to short stakes firmly driven at an angle into the ground.
Stakes shall be 5mm GI coated angle iron or 75mm mangrove. Stakes shall be a minimum length of
600mm and are to be driven deep enough to resist movement. A notch is to be made near the top of
each stake for the fastening of the guy wire. Stakes shall be positioned equally around the tree and shall
extend at least 300mm beyond the tree pit. Distance away from the tree shall be gauged on site to
provide firm and secure guying. Distance of stakes and final positions shall be finalized on site to
provide firm and secure guying.
iii. Each guy wire is to have one turnbuckle located near the fastening to the stake. Guy wires are to be kept
properly tension and adjusted to maintain the tree in a vertical position without guy wires being rigid.
c. Double Staking
i. Double staking shall be used for standard trees. Two 50mm x 50mm stakes shall be driven into the
ground vertically on either side of and outside the rootball of the tree so as to form a straight line with
the stem at the center. Stakes shall be driven in to penetrate the bottom of the tree pit and be deep
enough to resist lateral movement when tested. Stakes shall not extend beyond the lowest branch of the
tree and if necessary are to be sawn off at the top.
ii. Fastening or securing of the tree may be carried out by using either :
a) Cross bar a wooden cross bar of same section as the stakes is fastened in a horizontal
position to the outside of the stakes by nails or tying securely at a level below the lowest
branch. The tree is fastened to the cross bar with a single adjustable tie of an approved
rubberized or plastic type with a spacer and shall be fastened to prevent any chafing or
abrasion of the bark. Nails or fittings are not to be driven into the tree trunk.
b) Wire/Hose loops Two separate wire or rope loops are made about the stem just below the
lowest branch with each being fastened back to one of the vertical stakes. Each loop is to
have a protective outer covering or sheath of rubber hose to prevent chafing or abrasion of
the bark. The wire is to be fastened to the stakes in a manner that allows adjustment of the
tension to be made easily. Tension on each wire to be equal to maintain the tree in a vertical
position. The wire shall be 2.5mm PVC-coated GI wire, green colour.
iii. Where directed by the Landscape Architect the tree may be secured with a second set of loops at a
lower level.
d. Single Staking
Single Staking shall be used for field trees. A single 50mm x 50mm stake is driven vertically into the ground
150mm 250mm away from the tree. The stake is driven down beyond the base of the tree pit and shall be
firm when tested. The top of the stake shall be 100mm below the top of the tree. Ties are to be fastened to
avoid rubbing, chafing or abrasion of the bark.
Page 55 of 60
e. Dead Man Guying
Dead Man Guying shall be used where directed by Landscape Architect. This method of supporting trees is
for use in areas where other conventional methods of support are not feasible. Prior to backfilling two pairs of
preservation treated hardwood planks, minimum 100mm x 50mm, are laid across the top of the rootball at
right angles so that the trunk or stem is enclosed in a square. The timber planks should be positioned as far out
towards the edge of the rootball as possible but kept approximately 100mm in from the edge. Two pairs of
galvanized or stainless steel cables are then led over at right angles to the timber planks and the ends firmly
fastened into the ground at the base of the rootball or preferably fastened to a structure nearby. Twin buckles
at the mid point of each cable are installed to tightened the cables to a suitable degree. Cables should be
tightened only to hold the root-ball firm. Over-tightening may cause the rootball to settle deeper into the
ground than desired. Wherever Dead Man guying is directed refer to the Sub-Contract drawings for
particulars. If Dead Man guying is directed without a drawing the Landscape Contractor is to notify the
Landscape Architect.
f. Climber Wires
Climber wire for training climbing plants against walls shall be approved lightweight PVC coated wire mesh,
fixed at 600mm intervals to GI screw eyes. Maximum mesh coverage shall be 12 Months0mm high x 2400mm
wide. The climbing plants shall be trained through the wire mesh with the shoots directed upwards and tied.
C. WATERING OF ALL PLANTS
After planting of all plants are to be thoroughly watered using enough water to soak the ground all around the
rootball. After the water has percolated away leaving the surface relatively dry the soil is to be lightly
cultivated to give an even soil tilth.
D. MULCHING
After completion of planting, watering and light cultivation operations, a 50mm deep layer of approved
mulch shall be spread over all planting areas except turf and groundcover beds. Mulching is to be done within
2 days of completing planting and watering in. The cost of mulching is cleared to be included in the unit rates
for planting.
E. FERTILIZING
After planting and before the commencement of maintenance operations all planting areas will be fertilized at
three month intervals. Planting beds and pits shall be fertilized with an approved slow release fertilizer at the
rate of :
Trees : 250gm per tree
Shrubs/Climbers : 50gm per plant or 50gms/m2
Groundcover : 50gm per square meter
Herbaceous/Rooted shoots : spread around the base of the plants
Turf areas shall receive area 46.0.0 at a rate of 1kg/100m2. All fertilized areas are to be watered immediately
after fertilizer application
F. DISEASE CONTROL
The Landscape Contractor shall take all necessary precautions to prevent or eradicate any outbreak of disease
or insect attack.
G. PLANTING INTO TURF AREAS
Page 56 of 60
Where planting is to be carried out in areas of turf, the turf shall be carefully cut to the size of the tree or shrub
pit, rolled and stored for re-use, being kept moist and in shade. After planting, turf shall be relaid around the
base of the plant. The Landscape Contractor shall replace any turf, which is damaged during planting
operations. Trees in turf areas shall receive a 15cm high plastic trunk collar to protect the trunk from damage
during turf cutting.
H. PROTECTION OF PLANTED AREAS
The Landscape Contractor shall be responsible for protecting all planted areas. If it is necessary for the
Landscape Contractor to erect temporary protective fencing, the Landscape Contractor shall be responsible for
keeping the fencing in position and in good repair until the end of the maintenance period. Fencing proposals
shall be submitted to the Landscape Architect for approval.
I. MAINTENANCE PRIOR TO COMPLETION
i. After planting and prior to the onset of the maintenance period, the Landscape Contractor shall be
responsible for carrying out all necessary measures to ensure that the plant material thrives and
becomes established and that the landscape areas are kept in a clean and tidy condition.
ii. The Landscape Contractor shall allow for carrying out the following maintenance operations when
necessary prior to the onset of the maintenance period, all as specified in section 7 of this specification.
Replacement of dead/missing plants
Grass cutting
Watering
Cultivation and loosening of soil
Weeding
Pruning and clipping
Firming up and adjustment stakes and ties
Eradication of pest or insect attack
Top drawing and mulching
Fertilizing
iii. The Landscape Contractor shall be responsible for replacing any plants which fail to survive as a result
of inadequate maintenance operations, poor workmanship or poor quality of plant material prior to
completion
iv. The Certificate of completion will not be issued until all plans scheduled on the Drawings and Schedule
of Works are installed in a healthy condition in the manner specified.
Page 57 of 60
SECTION:6
SPECIFICATION OF PLANTING MATERIALS & BILL
OF QUANTITIES
Page 58 of 60
MahindraWorldCityJaipur
BILLOFQUANTITIESFORPLANTATIONWORKINLIGHTENGINEERINGZONE
No.of
SNO ABBREVIATIONS Description/NameoftheShrubs Plantsin1 Unit PhaseI PhaseII TotalQuantity RateinRs. AmountinRs
Sq.mtArea Quantity Quantity
TOTALAREAINLE(Sq.mt) 153565.43 113775.77
I.SHRUBS PLANTATION
A SOIL PREPARATION Soil Preparation for Shrubs should ideally be CUM 21473.46 15939.45 37415.00
prepared with existing soil+Upto 25-50 mm thk
layer of decomposed farmyard manure mixed
thoroughly with ,sulphur,gypsum,Reagent or any
other additive as required
B MANURING 25-50 mm thk on planting beds prior to mixing CUM 3578.91 2656.58 6240.00
with soil
C PLANTING TotalAreainSq.mt&TotalQtyinNosofPlants
1 ALOVER ALOE VERA 3 SQmt 50.00 43.00 93.00
0.5m overall ht @1m c/c
2 AGAAME AGAVE AMERICANA 3 SQmt 76.00 32.00 108.00
1m ht @4m c/c
3 AGAATT AGAVE ATTENUATA 3 SQmt 25.00 15.00 40.00
0.8m ht @2m c/c
4 ACOCAL ACORUS CALAMUS 3 SQmt 851.20 786.00 1640.00
0.6m O.H @0.6m SPC
5 BOUPIN BOUGAINVILLEA SPECTABILIS PINK 5 SQmt 170.00 170.00
0.6m overall ht @0.6m SPC
6 BOURED BOUGAINVILLEA SPECTABILIS RED 5 SQmt 10660.00 9843.00 20503.00
7 BOUWHI BOUGAINVILLEA SPECTABILIS WHITE 5 SQmt 5973.50 5222.50 11196.00
8 CLEINE CLERODENDRON INERME 12 SQmt 4904.00 3614.00 8518.00
9 CARCAR CARRISSA CARANDUS 6 SQmt 1981.00 1509.00 3490.00
10 CAEPULYEL CAESALPINIA PULICHERRIMA YELLOW 3 SQmt 2466.00 1957.00 4423.00
11 CAEPULORA CAESALPINIA PULICHERRIMA ORANGE 3 SQmt
12 CALPOR CALLIANDRA PORTORICENS 3 SQmt
13 CALBRI CALLIANDRA BRIVIPES 3 SQmt 2297.00 2297.00
14 CALHAE CALLIANDRA HAEMATOCEPHALUS 5 SQmt
15 CYPALT CYPERUS ALTERNIFOLIUS 3 SQmt 578.00 552.00 1130.00
16 EUPMIL EUPHORBIA MILLI 12 SQmt 1684.00 945.00 2629.00
0.45m O.H @0.3m SPC
17 EUPTIR EUPHORBIA TIRUCALLI 6 SQmt 5819.00 4592.00 10411.00
0.6m O.H @0.45m SPC
18 EUPNER EUPHORBIA NERIIFOLIA 12 SQmt 2630.00 540.00 3170.00
0.6m O.H @0.45m SPC
19 EUPTRIRUB EUPHORBIA TRIGONA RUBRA 6 SQmt 7240.00 4187.00 11427.00
0.6m O.H @0.45m SPC
20 EUPANT EUPHORBIA ANTIQUARUM 3 SQmt
No.of
21 HOLSAN HOLMCKIOLDIA SANGUINEA 3 SQmt 1688.00 1688.00
0.6m O.H @0.6m SPC
22 JATPAN JATROPA PANDURIFOLIA 3 SQmt 480.00 480.00
0.6m O.H @0.6m SPC
23 KALBLO KALANCHOE BLOSSFELDIANA 12 SQmt
0.45m O.H @0.3m SPC
24 LAWINE LAWSONIA INERMIS 3 SQmt 1004.00 841.00 1845.00
0.6m O.H @0.6m SPC
25 NERRED NERIUM OLEANDER RED 3 SQmt 1845.00 2034.00 3879.00
0.6m O.H @0.6m SPC
26 NERDWF 3 SQmt
27 NERPIN NERIUM OLEANDER PINK 3 SQmt 6216.00 5348.00 11564.00
0.6m O.H @0.6m SPC
28 NERWHI 3 SQmt
29 PENRUERED PENNISETUM REUPELLI RED 6 SQmt 4873.00 4816.00 9689.00
0.45m O.H @0.45m SPC
30 PENRUEGREEN PENNISETUM REUPELLI GREEN 6 SQmt 4303.50 4175.00 8480.00
0.45m O.H @0.45m SPC
31 PIDTIT PEDILIANTHUS TITHYMALOIDES 12 SQmt
0.45m O.H @0.3m SPC
32 SANTRI SANSEIVERA TRIFASCIATA 6 SQmt 1910.00 1850.00 3760.00
0.45m O.H @0.3m SPC
33 THEPER THEVETIA PERUVIANA 3 SQmt 1744.00 1744.00
1m O.H @0.6m SPC
34 VERELO VERNONIA ELEGANS 3 SQmt
0.6m O.H @0.6m SPC
35 YUCGLO YUCCA GLORIOSA 3 SQmt 110.00 230.00 340.00
0.8m O.H @2m c/c
TotalofPartI
II .PRIMARY & SECONDARY TREES
A Soil Preparation Soil Preparation for Tree Pit Size - CUM 570.00
1000mmX1000mmX1500mm ; Soil Preparation &
Mix has 1/3rd local excavated soil+1/3rd imported
garden soil+1/3rd decomposed farmyard
manure,Gypsum,Reagent or any other additived
as required
B Plantation 3000-3500 mm overall ht. 40-50 mm trunk caliper

(Stem Diameter)
1 ALSSCH ALSTONIA SCHOLARIS Nos 60.00
2 AZAIND AZADIRACHTA INDICA Nos 75.00
3 CASSIA CASSIA SIAMEA Nos 75.00
4 PONPIN PONGOMIA PINNATA Nos 120.00
5 PLURUB PLUMERIA ALBA Nos 10.00
6 PLURUB PLUMERIA RUBRA Nos 10.00
7 FICREL FICUS RELIGOSA Nos 15.00
8 BANYAN BANYAN TREE Nos 15.00
No.of
TotalofPartII
III .LAWN PLANTATION
1 SOIL PREPARATION Soil Preparation for Shrubs should ideally be CUM 24596.17 18193.28 42790.00
prepared with existing soil+Upto 25 mm thk layer
of decomposed farmyard manure mixed
other additive as required-
2 MANURING 25-50 mm thk on planting beds prior to mixing CUM 2049.68 1516.11 3570.00
with soil
3 LAWN PLANTATION WITH Thelawnshallbeplantedwithsmoothsurface SQmt 81987.23 60644.27 142640.00
SELECTION-1 formationusingrollerafterpropergrading
TotalofPartIII
IV .ROCKS
1 ROCKS Boulders & Rocks in form of Blocks- Nos. 50.00 75.00 125.00
Transportation from Quarry and placing on the
desired location-Size of Rock/Boulders : 1-1.2
Mtr high and circumference approx-8-12 mtrs
TotalofPartIV
TOTALofPart(I+II+III+IV)
NOTE:
1.WaterShallbeSuppliedbyMWCJwithin1to2KMLeadfromtheSite,TheTenderertobeprovideallmanpower&EquipmentforWateringthePlants
2.CostofPlantingMaterials&Planting30%ofTotalValueTobeprocessedforpaymentafter1monthofPlantingatsite
3.CostofMaintenance70%ofTotalValuefor12MonthsMaintenancestartfromthedateofcertification
4.PeriodofCompletion3Months+12monthsmaintenancepaybaleasperabove
BILLOFQUANTITIESFORPLANTATIONWORKINHANDICRAFTZONE
No.of
TOTALAREAINHC(Sq.mt) 200611.00 26518.00
I.SHRUBS PLANTATION
with soil
1 ALOVER ALOE VERA 3 SQmt
2 AGAAME AGAVE AMERICANA 3 SQmt 32.00 32.00
1m ht @4m c/c
3 AGAATT AGAVE ATTENUATA 3 SQmt 48.00 48.00
0.8m ht @2m c/c
4 ACOCAL ACORUS CALAMUS 3 SQmt 721.00 841.00 1562.00
0.6m O.H @0.6m SPC
5 BOUPIN BOUGAINVILLEA SPECTABILIS PINK 5 SQmt 1434.00 1434.00
6 BOURED BOUGAINVILLEA SPECTABILIS RED 5 SQmt
8 CLEINE CLERODENDRON INERME 12 SQmt 7091.00 7091.00
9 CARCAR CARRISSA CARANDUS 6 SQmt 755.00 755.00
10 CAEPULYEL CAESALPINIA PULICHERRIMA YELLOW 3 SQmt 2268.00 2268.00
13 CALBRI CALLIANDRA BRIVIPES 3 SQmt 8314.00 8314.00
14 CALHAE CALLIANDRA HAEMATOCEPHALUS 5 SQmt 7207.00 7207.00
15 CYPALT CYPERUS ALTERNIFOLIUS 3 SQmt 526.00 552.00 1078.00
16 EUPMIL EUPHORBIA MILLI 12 SQmt
0.45m O.H @0.3m SPC
17 EUPTIR EUPHORBIA TIRUCALLI 6 SQmt 3426.00 3426.00
0.6m O.H @0.45m SPC
18 EUPNER EUPHORBIA NERIIFOLIA 12 SQmt
0.6m O.H @0.45m SPC
19 EUPTRIRUB EUPHORBIA TRIGONA RUBRA 6 SQmt
0.6m O.H @0.45m SPC
20 EUPANT EUPHORBIA ANTIQUARUM 3 SQmt 2996.00 2996.00
No.of
21 HOLSAN HOLMCKIOLDIA SANGUINEA 3 SQmt
0.6m O.H @0.6m SPC
22 JATPAN JATROPA PANDURIFOLIA 3 SQmt 2621.00 2621.00
0.6m O.H @0.6m SPC
23 KALBLO KALANCHOE BLOSSFELDIANA 12 SQmt 1431.00 1431.00
0.45m O.H @0.3m SPC
24 LAWINE LAWSONIA INERMIS 3 SQmt
0.6m O.H @0.6m SPC
0.6m O.H @0.6m SPC
26 NERDWF 3 SQmt
27 NERPIN NERIUM OLEANDER PINK 3 SQmt 3528.00 1848.00 5376.00
0.6m O.H @0.6m SPC
28 NERWHI 3 SQmt
0.45m O.H @0.45m SPC
0.45m O.H @0.45m SPC
31 PIDTIT PEDILIANTHUS TITHYMALOIDES 12 SQmt 948.00 948.00
0.45m O.H @0.3m SPC
32 SANTRI SANSEIVERA TRIFASCIATA 6 SQmt 1070.00 1292.00 2362.00
0.45m O.H @0.3m SPC
33 THEPER THEVETIA PERUVIANA 3 SQmt 8523.00 8523.00
1m O.H @0.6m SPC
0.6m O.H @0.6m SPC
35 YUCGLO YUCCA GLORIOSA 3 SQmt 120.00 120.00
0.8m O.H @2m c/c
TotalofPartI
II .PRIMARY & SECONDARY TREES
A Soil Preparation Soil Preparation for Tree Pit Size - CUM 570.00
1000mmX1000mmX1500mm ; Soil Preparation &
Mix has 1/3rd local excavated soil+1/3rd imported
garden soil+1/3rd decomposed farmyard
manure,Gypsum,Reagent or any other additived
as required
B Plantation 3000-3500 mm overall ht. 40-50 mm trunk caliper

(Stem Diameter)
1 ALSSCH ALSTONIA SCHOLARIS Nos 60.00
2 AZAIND AZADIRACHTA INDICA Nos 75.00
3 CASSIA CASSIA SIAMEA Nos 75.00
4 PONPIN PONGOMIA PINNATA Nos 120.00
5 PLURUB PLUMERIA ALBA Nos 10.00
6 PLURUB PLUMERIA RUBRA Nos 10.00
7 FICREL FICUS RELIGOSA Nos 15.00
8 BANYAN BANYAN TREE Nos 15.00
No.of
TotalofPartII
III .LAWN PLANTATION
1 SOIL PREPARATION Soil Preparation for Shrubs should ideally be CUM 40804.20 40805.00
2 MANURING 25-50 mm thk on planting beds prior to mixing CUM 3400.35 3410.00
with soil
TotalofPartIII
IV .ROCKS
1 ROCKS Boulders & Rocks in form of Blocks- Nos. 60.00 60.00 120.00
TotalofPartIV
TOTALofPart(I+II+III+IV)
NOTE:
BILLOFQUANTITIESFORPLANTATIONWORKINUNNOTIFIEDAREA
No.of
I.SHRUBS PLANTATION
with soil
1 ALOVER ALOE VERA 3 SQmt
2 AGAAME AGAVE AMERICANA 3 SQmt 24.00 24.00
1m ht @4m c/c
3 AGAATT AGAVE ATTENUATA 3 SQmt 20.00 20.00
0.8m ht @2m c/c
4 ACOCAL ACORUS CALAMUS 3 SQmt 786.00 786.00
0.6m O.H @0.6m SPC
5 BOUPIN BOUGAINVILLEA SPECTABILIS PINK 5 SQmt
6 BOURED BOUGAINVILLEA SPECTABILIS RED 5 SQmt
8 CLEINE CLERODENDRON INERME 12 SQmt 7487.00 7487.00
9 CARCAR CARRISSA CARANDUS 6 SQmt 1200.00 1200.00
10 CAEPULYEL CAESALPINIA PULICHERRIMA YELLOW 3 SQmt 934.00 934.00
13 CALBRI CALLIANDRA BRIVIPES 3 SQmt
14 CALHAE CALLIANDRA HAEMATOCEPHALUS 5 SQmt 1788.00 1788.00
15 CYPALT CYPERUS ALTERNIFOLIUS 3 SQmt 552.00 552.00
16 EUPMIL EUPHORBIA MILLI 12 SQmt
0.45m O.H @0.3m SPC
17 EUPTIR EUPHORBIA TIRUCALLI 6 SQmt
0.6m O.H @0.45m SPC
18 EUPNER EUPHORBIA NERIIFOLIA 12 SQmt
0.6m O.H @0.45m SPC
19 EUPTRIRUB EUPHORBIA TRIGONA RUBRA 6 SQmt
0.6m O.H @0.45m SPC
20 EUPANT EUPHORBIA ANTIQUARUM 3 SQmt 1712.00 1712.00
No.of
21 HOLSAN HOLMCKIOLDIA SANGUINEA 3 SQmt
0.6m O.H @0.6m SPC
22 JATPAN JATROPA PANDURIFOLIA 3 SQmt
0.6m O.H @0.6m SPC
23 KALBLO KALANCHOE BLOSSFELDIANA 12 SQmt
0.45m O.H @0.3m SPC
24 LAWINE LAWSONIA INERMIS 3 SQmt
0.6m O.H @0.6m SPC
0.6m O.H @0.6m SPC
26 NERDWF 3 SQmt
27 NERPIN NERIUM OLEANDER PINK 3 SQmt 1848.00 1848.00
0.6m O.H @0.6m SPC
28 NERWHI 3 SQmt
0.45m O.H @0.45m SPC
0.45m O.H @0.45m SPC
31 PIDTIT PEDILIANTHUS TITHYMALOIDES 12 SQmt 520.00 520.00
0.45m O.H @0.3m SPC
32 SANTRI SANSEIVERA TRIFASCIATA 6 SQmt
0.45m O.H @0.3m SPC
33 THEPER THEVETIA PERUVIANA 3 SQmt
1m O.H @0.6m SPC
0.6m O.H @0.6m SPC
35 YUCGLO YUCCA GLORIOSA 3 SQmt
0.8m O.H @2m c/c
TotalofPartI
II .LAWN PLANTATION
1 SOIL PREPARATION Soil Preparation for Shrubs should ideally be CUM 14624.10 7348.35 40805.00
2 MANURING 25-50 mm thk on planting beds prior to mixing CUM 1218.68 612.36 3410.00
with soil
TotalofPartII
III .ROCKS
1 ROCKS Boulders & Rocks in form of Blocks- Nos. 20.00 20.00
TotalofPartIII
No.of
TOTALofPart(I+II+III)
NOTE:
SECTION: 7
LANDSCAPE DRAWINGS
Page 59 of 60

Tender For Landscape Plantation Works PDF

Uploaded by

Tender For Landscape Plantation Works PDF

Uploaded by

TENDER DOCUMENT

Mahindra World City (Jaipur)Ltd

JURONG Consultants Pte Site Concepts International Pte

LANDSCAPING-PLANTATION WORKS in Mahindra World City, Jaipur

SECTION-1 : TENDER NOTIFICATION

SECTION-2 : FORMS FOR TENDERER DECLARATION

SECTION-3 : PROJECT DESCRIPTION

SECTION-4 : CONDITIONS OF CONTRACT

SECTION-5 : SPECIAL CONDITIONS OF CONTRACT

SECTION-6 : PLANTING MATERIAL SPECIFICATION & BILL OF QUANTITIES

SECTION-7 : LANDSCAPE DRAWINGS

1. NOTICE INVITING TENDER

1. (a) NAME OF WORK Landscape (Softscape) Works @ MAHINDRA WORLD CITY @

LIGHT ENGINEERING SECTOR SPECIFIC SEZ

PACKAGE-1: AREA OF LANDSCAPE =Approx. 153,565 sq.mt

HANDICRAFT SECTOR SPECIFIC SEZ

DOMESTIC TARRIF AREA(DTA)

Area under Development Phase I Phase II

8. TENDER FORMS a) No corrections or alterations in the form, nor in the conditions

The tender shall be addressed to:

Deputy General Manager (Contracts), Project office, MAHINDRA

e) In order to afford prospective tenderer reasonable time to take the

The tender to be prepared and submitted by the tenderer to the Employer

i) A covering letter from the Tenderer detailing the various

with seal of the organization.

5. CORRECTION OF a) Tenders determined to be substantially responsive to be checked by

6. DISCREPANCIES a) In case of any inconsistency between bill of quantities, performance

7. UNSUCCESSFUL The earnest money deposits of the unsuccessful tenderers will be

f) Withdrawal of the tender when it is once accepted, or failure on the

3. GENERAL CONDITIONS TO THE CONTRACTORS

a) The Conditions of Contract, as stipulated hereunder, shall bind the Contractor.

SIGNATURES AND SEALS:

Contractor: M/s. ____________________ Employer: M/s. ____________________

FORM OF ARTICLES OF AGREEMENT

ARTICLES OF AGREEMENT made the __________ day of __________2010,

NOW IT IS HEREBY AGREED AS FOLLOWS:

AS WITNESS OUR HANDS THIS __________ DAY OF __________ 2010.

Signed by the said CONTRACTOR Signed by the said EMPLOYER

FORM OF DECLARATION BY THE TENDERER Date: ------------------

----------------------------------------------------------------------. The Head (Infra),

. Mahindra World City(Jaipur) Ltd

a) General description - Construction of Softscape Works at MAHINDRA WORLD

c) Security Deposit to be deducted from the

d) Time allowed for completion of ..

e) Amount put to tender - Rs. ...

DATED THE __________ DAY OF _______________ 2011.

Signature of the Contractor

(Seal and address)

APPENDIX HEREIN REFERRED TO

SL. NO. TERM USED DESCRIPTION

2. Date of Completion : As per the schedule of the Work -in stages-Milestone

4. Retention Percentage in the interim bills : 10% (ten percent)

8. Period of Final Measurements of work : 15 Days after submission of Stage Completion

Signature & Seal

CONTRACTOR/AUTHORIZED SIGNATORY OF CONTRACTING FIRM

1. BRIEF PROJECT DESCRIPTION MAHINDRA WORLD CITY @ JAIPUR,

Sl. Terms of Reference Description

(a) Deduct, at the percentage mentioned below, of all money

(b) To hold such deductions as further Security Deposit.

E.M.D. Earnest Money Deposit - Rs 50,000/ for the work at

Any instructions given verbally shall be noted in the Instruction Book

i) The variation or modification of the design, quality or

Any alterations made to the work made based on technical;/aesthetic

i) Increase or decrease the quantity of any work included in the

Architect/Site-In-Charge and payment to be on sole discretion of the

In the absence of similar items in Contract, the Contractor shall within

at his own expense, or in default, the Site-In-Charge or other competent

Figures of dimensions shall be followed in preference to scale

All drawings, tracings, photo prints, blue prints and writings

The drawings maintained in the site are to be carefully mounted on

The Contract shall remain in the custody of the Employer, and a

The completion period, as stated in the Contract, shall be strictly

The time limit for completion of the work shall be extended

If the delay is attributable to reasons beyond the control of the

NOTE: If the Site-In-Charge considers it necessary, he shall also be

To employ labour paid by the MAHINDRA WORLD CITY

Contractor: M/s. Employer: M/s.

ARTICLES OF AGREEMENT made the day of 2010,

AS WITNESS OUR HANDS THIS DAY OF 2010.

DATED THE DAY OF _____ 2011.